Construction Contract Agreement Form Template for England and Wales

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Construction Contract Agreement Form

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Construction Contract Agreement Form

"I need a Construction Contract Agreement Form for a residential development project in Manchester with a contract value of £5M, including specific provisions for sustainable materials and renewable energy installations, with work scheduled to commence in March 2025."

Document background

The Construction Contract Agreement Form is essential for any construction project in England and Wales, providing a comprehensive framework for the relationship between employers and contractors. This document is crucial when undertaking any significant construction work, whether commercial, residential, or industrial. It incorporates mandatory provisions from the Housing Grants, Construction and Regeneration Act 1996, CDM Regulations 2015, and other relevant legislation. The agreement covers essential elements including scope of works, payment terms, programme, variations, and dispute resolution procedures, while ensuring compliance with English and Welsh construction law requirements.

Suggested Sections

1. Parties: Identification and details of the contracting parties (employer and contractor)

2. Background: Context of the construction project and purpose of the agreement

3. Definitions: Key terms used throughout the contract

4. Scope of Works: Detailed description of the construction works to be performed

5. Contract Sum: Price, payment terms, and mechanism for variations

6. Programme and Completion: Project timeline, completion dates, and liquidated damages

7. Contractor Obligations: Key responsibilities and duties of the contractor

8. Employer Obligations: Key responsibilities and duties of the employer

9. Insurance and Liability: Required insurance coverage and liability provisions

10. Termination: Circumstances and procedures for contract termination

Optional Sections

1. Design Responsibility: Used when contractor has design obligations in design and build contracts

2. Performance Bond: Requirements for performance security in high-value projects or where risk mitigation is required

3. Parent Company Guarantee: Additional security from contractor's parent company when dealing with subsidiary companies

4. Collateral Warranties: Third-party rights and warranties when third-party beneficiaries are involved

Suggested Schedules

1. Schedule of Works: Detailed specification of construction works

2. Programme: Detailed timeline and milestone dates

3. Payment Schedule: Breakdown of payments and milestone payments

4. Site Information: Details about the construction site and conditions

5. Drawing Schedule: List of all relevant drawings and specifications

6. Insurance Requirements: Detailed insurance specifications and levels

7. Form of Bonds/Guarantees: Templates for required security documents

8. Quality Standards: Specific quality requirements and standards

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Commercial Construction
Residential Development
Infrastructure
Industrial Construction
Public Sector Construction
Healthcare Construction
Education Construction
Retail Development

Relevant Teams

Legal
Construction
Commercial
Operations
Procurement
Project Management
Risk Management
Finance
Compliance
Technical Services

Relevant Roles

Construction Manager
Project Director
Commercial Director
Contracts Manager
Quantity Surveyor
Project Manager
Construction Director
Legal Counsel
Risk Manager
Procurement Manager

Industries

Construction Act 1996: Housing Grants, Construction and Regeneration Act 1996, as amended by the Local Democracy, Economic Development and Construction Act 2009. Covers payment provisions, adjudication rights, and notice requirements.

Supply of Goods and Services Act 1982: Governs the quality of work and requirements for reasonable care and skill in construction contracts.

Contracts (Rights of Third Parties) Act 1999: Regulates third-party rights and their ability to enforce terms of the construction contract.

Late Payment of Commercial Debts Act 1998: Sets out payment terms and interest provisions for late payments in commercial contracts.

CDM Regulations 2015: Construction (Design and Management) Regulations covering health and safety requirements, principal contractor duties, and client obligations.

Public Contracts Regulations 2015: Regulations governing public sector construction projects and procurement processes.

Building Regulations 2010: Sets standards for building work and compliance requirements in construction projects.

Standard Form Contracts: Industry standard forms such as JCT (Joint Contracts Tribunal) or NEC (New Engineering Contract) serving as reference points.

Common Law Principles: Legal principles regarding contract formation, breach, damages, and variations established through case law.

Party Wall Act 1996: Legislation governing works affecting party walls and adjacent properties.

Health and Safety at Work Act 1974: Primary legislation for workplace health and safety requirements in construction projects.

Environmental Regulations: Various environmental protection requirements and compliance standards for construction works.

VAT and Tax Regulations: Tax implications and VAT requirements specific to construction contracts and projects.

Insurance Requirements: Mandatory and recommended insurance coverage for construction projects including professional indemnity and contractors all-risk insurance.

Planning Legislation: Requirements for obtaining necessary planning permissions and complying with local planning regulations.

How a Sales & Marketing Lead uses Genie AI to reduce contract drafting time by 95%

Let's create your Construction Contract Agreement Form

Authors

Alex Denne

Find the exact document you need

Work Contracts For Independent Contractors

Subcontractor Agreement Payment Terms

Startup Contractor Agreement

Standard General Contractor Agreement

Standard Form Of Contract For Maintenance And Renovation Works

Standard Builders Contract

Spa Independent Contractor Agreement

Sound And Light Contracting Agreement

Snow Removal Service Contract

Short Contractor Agreement

Simple Engineering Contract

Simple Contractor Contract

Short Form Subcontractor Agreement

Simple Handyman Contract

Self Employed Cleaner Contract

Salon Contract For Employees

Sales Subcontractor Agreement

Real Estate Construction Contract

Prime Contractor Agreement

Preferred Contractor Agreement

Percentage Agreement Contract

Painting Subcontractor Contract

Part Time Contractor Agreement

Non Profit Contractor Agreement

Mining Contractor Agreement

Masonry Contract Agreement

Janitorial Subcontractor Agreement

IT Contractor Contract

Independent Sales Contract

Independent Contractor Separation Agreement

Housekeeping Services Agreement Contract

House Framing Contract

House Flipping Contractor Agreement

Home Remodel Contract

General Contract For Services Agreement

General Contract Agreement Between Two Parties

Framing Contractor Contract

Framework Agreement Contract

Fence Contract Agreement

Farm Labor Contractor Agreement

Electrician Service Contract

Construction Warranty Agreement

Construction Service Contract

Construction Contract Agreement Form

Contract For Cleaning Services Agreement

Contract Between Owner And Contractor

Contract Between Owner And Architect

Contract Agreement For Interior Works

Contractor Sales Commission Agreement

Contractor Retainer Agreement

Contractor NDA Agreement

Contractor Deposit Agreement Form

Contractor Carrier Lease Agreement

Civil Construction Contract Agreement

Carpenter Contract Agreement

Binding Agreement Contract

Basic Simple Subcontractor Agreement

Basic Construction Contract

Agreement Security Guard Contract

Agreement For Construction Of House

Agreement Between Contractor And Principal Employer

Agreement Between Architect And Contractor

Snow Removal Residential Contract

Roofing Repair Contract

Contract Agreement Between Client And Contractor

Subcontractor Equipment Use Agreement

Anesthesia Independent Contractor Agreement

Agreement Between Two Parties For Construction Contract

Janitorial Independent Contractor Agreement

Contractor Contract For Services

Freelance Subcontractor Agreement

Interpreter Independent Contractor Agreement

Client And Contractor Agreement

General Contractor Work Agreement

Residential Snow Removal Contract