Construction Contract Addendum Template Generator for the USA

Create a bespoke document in minutes,  or upload and review your own.

4.6 / 5
4.8 / 5

Let's create your Construction Contract Addendum Template

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Construction Contract Addendum Template

"I need a Construction Contract Addendum Template to modify an existing agreement with our subcontractor, increasing the project scope to include an additional floor and extending the completion deadline to March 2025, with corresponding price adjustments."

Document background
The Construction Contract Addendum Template serves as a critical tool in the U.S. construction industry for managing contract modifications. When circumstances require changes to an existing construction agreement, this document provides a standardized format for documenting modifications while ensuring legal compliance. It addresses common construction project changes such as scope adjustments, cost variations, timeline modifications, and specification updates, while maintaining alignment with both federal and state construction regulations.
Suggested Sections

1. Parties: Identification of all parties involved in the original contract and addendum

2. Background: Reference to original contract and reason for addendum

3. Definitions: Key terms used in the addendum

4. Scope of Changes: Detailed description of modifications to original contract

5. Effect on Original Agreement: Statement of which original terms remain in force

Optional Sections

1. Price Adjustments: Used when modification affects project costs - includes changes to contract price and payment terms

2. Schedule Modifications: Used when modification affects project duration - includes changes to project timeline and milestones

3. Additional Insurance Requirements: Used when scope changes require additional coverage - specifies new or modified insurance provisions

Suggested Schedules

1. Schedule A - Revised Scope of Work: Detailed description of modified work requirements and specifications

2. Schedule B - Revised Price Schedule: Updated pricing details, payment terms, and cost breakdown

3. Schedule C - Revised Project Timeline: Modified project schedule, milestones, and completion dates

4. Schedule D - Additional Specifications: New technical requirements, materials specifications, or construction details

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Relevant legal definitions
Clauses
Industries

Contract Common Law: Fundamental principles governing contract formation, enforcement, and interpretation in the United States legal system

Uniform Commercial Code: While primarily for goods, certain UCC provisions may apply to construction contracts, especially regarding materials and equipment

Davis-Bacon Act: Federal law requiring payment of prevailing wages on federally funded construction projects

OSHA Regulations: Occupational Safety and Health Administration standards that ensure workplace safety and health requirements in construction

Americans with Disabilities Act: Federal law requiring accessible design and construction standards in public accommodations and commercial facilities

Federal Acquisition Regulation: Comprehensive regulations for federal government construction procurement processes and contracts

State Construction Lien Laws: State-specific regulations governing mechanics liens and security interests for contractors, subcontractors, and suppliers

State Contractor Licensing: State-specific requirements for contractor qualification, registration, and maintaining valid licenses

State Building Codes: State-specific construction standards and requirements for building safety and compliance

State Insurance Requirements: State-specific mandatory insurance coverage levels and types for construction projects

State Labor Laws: State-specific regulations governing employment, wages, and working conditions in construction

State Prompt Payment Acts: State-specific laws governing timing and terms of payments in construction contracts

Local Building Codes: Municipality-specific construction requirements and permits needed for project execution

Environmental Regulations: Federal, state, and local environmental protection requirements affecting construction projects

Bonding Requirements: Performance and payment bond requirements for construction projects, particularly public works

Dispute Resolution Procedures: Legal framework for handling construction disputes through mediation, arbitration, or litigation

Change Order Procedures: Legal requirements for documenting and executing changes to the original construction contract

Material Price Escalation: Legal provisions addressing price fluctuations in construction materials and associated contract adjustments

Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Utility Addendum To Lease

A U.S. legal document that supplements a lease agreement by specifying utility responsibilities and payment arrangements between landlord and tenant.

find out more

Tenant Pet Agreement Form

A U.S. legal document that establishes terms and conditions for keeping pets in rental properties, supplementing the main lease agreement.

find out more

Tenant Occupied Property Addendum To Agreement Of Sale

A U.S.-governed addendum to a property sale agreement specifically addressing the transfer of tenant-occupied property and associated obligations.

find out more

Swimming Pool Lease Addendum

A U.S. legal document that supplements a lease agreement with specific terms and conditions for swimming pool use and maintenance.

find out more

Swimming Pool Addendum To Lease

A U.S. legal document that supplements a residential lease agreement by establishing rules and responsibilities for properties with swimming pools.

find out more

Storage Addendum To Lease

A U.S. legal document that modifies an existing lease to include terms for additional storage space provided to the tenant.

find out more

Simple Addendum Template

A U.S.-compliant template for modifying existing contracts through formal written amendments.

find out more

Short Term Lease Addendum

A U.S. legal document that modifies an existing lease agreement for a short-term period, subject to federal, state, and local rental regulations.

find out more

Short Sale Addendum

A U.S. legal document that modifies a purchase agreement to accommodate short sale terms and lender approval requirements.

find out more

Seller Name Change Addendum To Real Estate Contract

A U.S. legal document that amends a real estate contract to reflect the seller's legal name change while preserving the original contract's terms.

find out more

Seller Financing Addendum To Real Estate Purchase Contract

A U.S. legal document establishing terms for seller-provided financing in real estate transactions.

find out more

Seller Financing Addendum

A U.S. legal document establishing terms when a property seller provides financing to the buyer.

find out more

Sales Price Change Addendum

A U.S.-compliant legal document that modifies the price terms in an existing sales agreement while maintaining other original contract terms.

find out more

Roommate Lease Addendum

A U.S. legal document that modifies an existing lease to add new roommates and define their rights and responsibilities.

find out more

Roommate Addendum To Lease Rental Agreement

A U.S. legal document that formally adds new roommates to an existing lease agreement while defining shared responsibilities and obligations.

find out more

Residential Pet Agreement

A U.S. legal document that establishes terms and conditions for keeping pets in residential rental properties.

find out more

Residential Lease Addendum Template

A U.S. legal document that modifies or supplements an existing residential lease agreement while maintaining compliance with federal, state, and local housing laws.

find out more

Rental Pet Agreement Template

A U.S.-compliant agreement establishing terms for pet ownership in rental properties.

find out more

Rental Pet Agreement Form

A U.S. legal document establishing terms and conditions for keeping pets in rental properties, supplementing the main lease agreement.

find out more

Rental Pet Agreement

A U.S. legal agreement that establishes terms and conditions for keeping pets in rental properties, supplementing the main lease agreement.

find out more

Rental Lease Pet Addendum

A U.S. legal document supplementing a lease agreement that establishes terms and conditions for keeping pets in rental properties.

find out more

Rental Contract Extension Addendum

A U.S. legal document that extends an existing rental agreement's term while maintaining or modifying its original conditions.

find out more

Rental Arbitrage Lease Addendum

A U.S. legal document that modifies a lease agreement to permit and regulate short-term rental arbitrage operations.

find out more

Rental Agreement Extension Addendum

A U.S. legal document that extends an existing lease agreement's duration while maintaining or modifying original terms.

find out more

Rental Agreement Addendum To Extend Lease

A U.S. legal document that extends an existing lease agreement's duration while maintaining or modifying other terms of the original lease.

find out more

Rent Increase Lease Addendum

A U.S. legal document that modifies an existing lease agreement to implement and document a rent increase while maintaining compliance with applicable laws.

find out more

Real Estate Personal Property Addendum

A U.S. legal document specifying personal property items included in a real estate sale, supplementing the main purchase agreement.

find out more

Real Estate Name Change Addendum

A U.S. legal document that amends property records to reflect an owner's name change while maintaining clear chain of title.

find out more

Real Estate Contract Extension Form

A U.S. legal document that extends the termination date of an existing real estate purchase agreement while maintaining original contract terms.

find out more

Real Estate Contract Extension Addendum

A U.S. legal document that extends the timeline or modifies terms of an existing real estate purchase agreement.

find out more

Real Estate Contract Extension

A U.S. legal document that extends the timeline of an existing real estate purchase agreement while maintaining other original contract terms.

find out more

Real Estate Contract Amendment Template

A U.S.-compliant template for modifying existing real estate purchase agreements while maintaining legal validity under federal and state laws.

find out more

Real Estate Closing Date Addendum

A U.S. legal document that modifies the closing date in a real estate purchase agreement.

find out more

Real Estate Amendment Form

A U.S. legal document used to modify existing real estate contracts while maintaining compliance with federal and state regulations.

find out more

Real Estate Addendum To Extend Closing Date

A U.S. legal document that modifies the closing date in a real estate purchase agreement while maintaining other original contract terms.

find out more

Real Estate Addendum

A U.S. legal document that modifies or amends an existing real estate contract while maintaining compliance with federal and state property laws.

find out more

Purchase Price Addendum

A U.S.-compliant legal document that modifies the purchase price in an existing contract while maintaining other terms.

find out more

Purchase Contract Extension Addendum

A U.S. legal document that extends and potentially modifies an existing purchase agreement, governed by state laws and the UCC.

find out more

Purchase And Sale Addendum

A U.S. legal document that modifies or supplements an existing purchase and sale agreement.

find out more

Purchase Agreement Extension Addendum

A U.S. legal document that extends and potentially modifies an existing purchase agreement's terms and duration.

find out more

Purchase Agreement Addendum Template

A U.S.-compliant legal template used to modify existing purchase agreements while maintaining the validity of unchanged terms.

find out more

Project Addendum Template

A U.S.-compliant legal document used to modify existing project agreements by documenting agreed changes to scope, timeline, or budget.

find out more

Professional Addendum Template

A U.S.-compliant template for modifying existing professional services agreements through formal addenda.

find out more

Price Reduction Addendum To The Listing Agreement

A U.S. legal document that modifies the listing price in an existing real estate listing agreement.

find out more

Post Settlement Possession Addendum To Agreement Of Sale

A U.S. legal document that permits sellers to temporarily occupy property after closing, specifying terms and conditions of post-settlement possession.

find out more

Pool Addendum To Residential Lease Agreement

A U.S. legal document that supplements a residential lease agreement by establishing terms and conditions for pool usage and maintenance.

find out more

Pool Addendum To Lease

A U.S. legal document that supplements a residential lease agreement by establishing terms and conditions for pool usage and safety requirements.

find out more

Pool Addendum For Rental Agreement

A U.S. legal document supplementing a rental agreement that establishes rules and responsibilities for pool usage and maintenance.

find out more

Pet Policy Lease Addendum

A U.S. legal document that supplements a residential lease agreement by establishing terms and conditions for pet ownership in rental properties.

find out more

Pet Lease Agreement

A U.S.-compliant legal agreement governing the temporary transfer of pet care responsibilities between owner and caretaker.

find out more

Pet Agreement Template

A U.S.-compliant legal document establishing terms for pet ownership in rental properties, addressing both standard pets and service animals.

find out more

Pet Agreement For Rental Property

A U.S. legal document that supplements a residential lease agreement by establishing terms and conditions for keeping pets in rental properties.

find out more

Pet Agreement Contract

A U.S.-compliant legal agreement establishing terms for pet ownership in rental properties.

find out more

Pet Addendum To Residential Lease

A U.S. legal document that supplements a residential lease agreement by establishing terms and conditions for pet ownership in rental properties.

find out more

Pet Addendum Rental Agreement

A U.S. legal document that supplements a residential lease agreement by specifying terms and conditions for keeping pets in rental properties.

find out more

Personal Property Addendum To Real Estate Contract

A U.S. legal document that specifies personal property items included in a real estate sale.

find out more

Payment Addendum To Contract

A U.S. legal document that modifies payment terms in an existing contract while maintaining other original provisions.

find out more

Owners Pet Agreement

A U.S. legal agreement defining pet ownership rights, responsibilities, and obligations.

find out more

Name Change Addendum To Real Estate Contract

A U.S. legal document that modifies an existing real estate contract to reflect a party's legal name change while maintaining all other original contract terms.

find out more

Month To Month Addendum To Lease Agreement

A U.S. legal document that modifies an existing lease agreement to establish a month-to-month tenancy arrangement.

find out more

Mold Addendum To Lease

A U.S. legal document that supplements a lease agreement by addressing mold-related responsibilities and procedures between landlord and tenant.

find out more

Listing Contract Addendum

A U.S. legal document that modifies an existing real estate listing agreement between property owners and real estate agents.

find out more

Listing Addendum

A U.S. real estate document that modifies an existing listing agreement between property owners and real estate agents.

find out more

Addendum To Lease Template

A U.S. legal document that modifies an existing lease agreement while maintaining the validity of the original contract.

find out more

Addendum To Lease Removing A Tenant

A U.S.-compliant legal document that modifies an existing lease agreement to remove one tenant while maintaining the lease for remaining tenants.

find out more

Addendum To Lease Contract

A U.S. legal document that modifies an existing lease agreement while maintaining other original terms.

find out more

Addendum To Lease Agreement Month To Month

A U.S. legal document modifying an existing lease agreement to establish month-to-month tenancy terms.

find out more

Addendum To Lease Agreement Change Of Name

A U.S. legal document that updates a tenant's name on an existing lease agreement while maintaining all other original lease terms.

find out more

Addendum To Lease Agreement Adding Tenant

A U.S.-compliant legal document that adds a new tenant to an existing lease agreement while maintaining original terms and conditions.

find out more

Addendum To Lease Adding Tenant

A U.S. legal document that formally adds a new tenant to an existing lease agreement while maintaining original lease terms.

find out more

Addendum To Lease

A U.S. legal document that modifies an existing lease agreement while maintaining the validity of the original contract.

find out more

Addendum To Land Contract

A U.S. legal document that modifies an existing land contract while maintaining its core provisions.

find out more

Addendum To Independent Contractor Agreement

A U.S. legal document that modifies an existing independent contractor agreement while maintaining compliance with federal and state contractor laws.

find out more

Addendum To Home Purchase Agreement

A U.S. legal document that modifies or adds terms to an existing home purchase agreement, subject to federal and state real estate laws.

find out more

Addendum To Extend Lease

A U.S. legal document that extends an existing lease agreement between landlord and tenant, specifying new termination date and any modified terms.

find out more

Addendum To Employment Contract Salary

A U.S.-compliant legal document modifying an employee's salary terms in an existing employment contract.

find out more

Addendum To Employment Agreement

A U.S.-governed legal document that modifies specific terms of an existing employment agreement while maintaining other original terms.

find out more

Addendum To Deed Of Sale

A U.S. legal document that modifies or amends an existing deed of sale, subject to state property laws.

find out more

Addendum To Consulting Agreement

A U.S. legal document that modifies an existing consulting agreement while keeping other original terms intact.

find out more

Addendum To Commercial Lease Agreement Extension

A U.S. legal document that extends and potentially modifies an existing commercial lease agreement while maintaining original terms not specifically changed.

find out more

Addendum To Commercial Lease

A U.S. legal document that modifies an existing commercial lease agreement while maintaining other original terms.

find out more

Addendum To Change Purchase Price

A U.S. legal document that modifies the purchase price in an existing purchase agreement while maintaining all other original terms.

find out more

Addendum To Change Name On Contract

A U.S. legal document that modifies an existing contract to reflect a party's name change while maintaining all other original contract terms.

find out more

Addendum To Buy Sell Agreement

A U.S. legal document that modifies an existing Buy-Sell Agreement while maintaining other original terms.

find out more

Addendum To Bill Of Sale

A U.S. legal document that modifies or adds to an existing bill of sale, ensuring compliance with federal and state laws.

find out more

Addendum To Add Tenant To Lease

A U.S. legal document that formally adds a new tenant to an existing lease agreement while maintaining original lease terms.

find out more

Addendum To Add Buyer To Contract

A U.S. legal document that formally adds a new buyer to an existing contract while maintaining original terms and conditions.

find out more

Addendum To Add Additional Tenant To Lease

A U.S. legal document that formally adds a new tenant to an existing lease agreement while maintaining original lease terms.

find out more

Addendum To Add Additional Buyer

A U.S. legal document that adds an additional buyer to an existing purchase agreement, establishing their rights and obligations under the original contract.

find out more

Addendum Tenancy Agreement

A U.S. legal document that modifies an existing lease agreement while maintaining compliance with federal, state, and local housing laws.

find out more

Addendum Template For Contract Agreement

A U.S.-compliant template for modifying existing contracts through formal addenda.

find out more

Addendum Loan Agreement

A U.S. legal document that modifies terms of an existing loan agreement while maintaining compliance with federal and state lending regulations.

find out more

Addendum Home Purchase

A U.S. legal document that modifies terms in an existing home purchase agreement.

find out more

Addendum For (Real Estate)

A U.S. legal document that modifies or adds terms to an existing real estate contract while maintaining compliance with federal and state property laws.

find out more

Add Tenant To Lease Addendum

A U.S. legal document that formally adds a new tenant to an existing lease agreement while maintaining original lease terms.

find out more

Contingency Addendum Sale Of (Real Estate)

A U.S. legal document that adds specific conditions to a real estate purchase agreement that must be met for the sale to proceed.

find out more

Construction Contract Amendment Template

A U.S.-compliant template for modifying existing construction contracts, documenting changes to scope, timeline, or costs.

find out more

Construction Contract Addendum Template

A U.S.-compliant template for modifying existing construction contracts, documenting changes to scope, pricing, or timeline.

find out more

Commercial Lease Extension Addendum

A U.S. legal document that extends the term of an existing commercial lease agreement while maintaining or modifying other lease terms.

find out more

Commercial Lease Amendment Template

A U.S. legal document used to modify existing commercial lease agreements while maintaining other original terms.

find out more

Download our whitepaper on the future of AI in Legal

By providing your email address you are consenting to our Privacy Notice.
Thank you for downloading our whitepaper. This should arrive in your inbox shortly. In the meantime, why not jump straight to a section that interests you here: https://www.genieai.co/our-research
Oops! Something went wrong while submitting the form.

Genie’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; Genie’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

Our bank-grade security infrastructure undergoes regular external audits

We are ISO27001 certified, so your data is secure

Organizational security

You retain IP ownership of your documents

You have full control over your data and who gets to see it

Innovation in privacy:

Genie partnered with the Computational Privacy Department at Imperial College London

Together, we ran a £1 million research project on privacy and anonymity in legal contracts

Want to know more?

Visit our Trust Centre for more details and real-time security updates.