All Countries
Commercial
Construction Contract Addendum

Construction Contract Addendum Template for United Arab Emirates

Create a bespoke document in minutes,  or upload and review your own.

4.6 / 5
4.8 / 5

Let's create your Construction Contract Addendum

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Construction Contract Addendum Template

"I need a Construction Contract Addendum Template for a UAE hotel development project where we're adding three additional floors to the original scope, with an expected completion extension to June 2025, including updated payment milestones and additional safety requirements for high-rise construction."

Celebrated by
Collaborations with
Investors
Document background
The Construction Contract Addendum Template is designed for use in the United Arab Emirates when parties need to modify existing construction contracts. It is particularly relevant when project scope changes, timeline adjustments, or price modifications are required during the construction phase. The template ensures compliance with UAE Federal Law No. 5 of 1985 (Civil Code), especially Articles 872-896 governing construction contracts (Muqawala), and incorporates relevant emirate-specific regulations. It includes provisions for documenting changes, obtaining necessary approvals, and maintaining proper record-keeping as required by UAE construction law. The template is structured to accommodate both major and minor modifications while maintaining the integrity of the original contract and ensuring all changes are properly documented and legally enforceable under UAE law.
Suggested Sections

1. Parties: Identification of all parties to the original contract and addendum, including full legal names, addresses, and registration details as per UAE requirements

2. Background: Reference to the original contract, including date, purpose, and reason for the addendum

3. Definitions: Key terms used in the addendum, including any new terms not defined in the original contract

4. Amendment Details: Specific changes to the original contract, clearly stating what is being modified, added, or deleted

5. Effect on Original Contract: Statement confirming which original contract provisions remain in force and which are superseded

6. Consideration: Details of any additional payment or consideration for the changes, if applicable

7. Time Impact: Effect of the amendments on project timeline, completion dates, and milestones

8. Authorization: Confirmation of authority to execute the addendum and any required approvals

9. Governing Law and Jurisdiction: Confirmation of UAE law application and jurisdiction

10. Execution: Signature blocks and execution requirements as per UAE law

Optional Sections

1. Additional Security: Include when modifications require new or additional performance bonds or guarantees

2. Insurance Modifications: Use when changes affect insurance requirements or coverage

3. Subcontractor Provisions: Include when amendments affect subcontractor relationships or requirements

4. Design Modifications: Include for changes affecting design responsibilities or specifications

5. Force Majeure Updates: Use when modifying force majeure provisions in light of new circumstances

6. Environmental Compliance: Include when changes affect environmental obligations or requirements

7. Dispute Resolution Modifications: Use when altering dispute resolution procedures

8. Health and Safety Updates: Include when modifications affect health and safety requirements

Suggested Schedules

1. Schedule of Amendments: Detailed list of all specific changes to original contract clauses

2. Revised Price Schedule: Updated pricing details, including any new rates or adjustments

3. Modified Program of Works: Updated project timeline and milestone dates

4. Technical Modifications: Detailed technical changes to specifications or requirements

5. Updated Drawing Register: List of new or modified drawings applicable to the changes

6. Revised Bill of Quantities: Modified quantities and measurements reflecting the changes

7. Authority Approvals: Copies of any required regulatory or authority approvals for the changes

8. Payment Schedule Revisions: Modified payment terms and schedules

9. Insurance Certificates: Updated insurance documentation if required by the changes

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Linkedin in social icon imageX social icon image
alex.den.21@genieai.co
Relevant legal definitions
Addendum
Original Contract
Effective Date
Modified Works
Additional Works
Revised Completion Date
Extension of Time
Contract Price Adjustment
Variation
Modified Specifications
Updated Program
Revised Bill of Quantities
Modified Drawings
Additional Documents
Original Parties
New Parties
Modified Terms
Superseded Provisions
Surviving Provisions
Additional Services
Revised Scope
Modified Deliverables
Updated Schedule
Price Escalation
Time Impact
Force Majeure Event
Modified Payment Terms
Additional Requirements
Revised Milestones
Quality Standards
Site Conditions
Material Changes
Substantial Completion
Taking Over
Defects Liability Period
Project Manager
Engineer
Consultant
Employer's Representative
Contractor's Representative
Clauses
Interpretation
Amendment Scope
Contract Modifications
Time Extensions
Price Adjustments
Payment Terms
Variations
Additional Works
Performance Security
Insurance
Force Majeure
Health and Safety
Environmental Compliance
Quality Control
Materials and Workmanship
Site Access
Testing and Inspection
Completion and Handover
Defects Liability
Warranties
Intellectual Property
Confidentiality
Dispute Resolution
Governing Law
Notices
Assignment
Subcontracting
Compliance with Laws
Labor Requirements
Documentation
Authority Approvals
Risk Allocation
Indemnification
Termination
Severability
Entire Agreement
Counterparts
Electronic Execution
Relevant Industries

Construction

Real Estate Development

Infrastructure

Commercial Property

Residential Development

Industrial Construction

Healthcare Construction

Hospitality Development

Education Facilities

Retail Development

Energy and Utilities

Transportation

Relevant Teams

Legal

Construction

Commercial

Operations

Procurement

Risk Management

Project Management

Contract Administration

Technical Services

Compliance

Finance

Relevant Roles

Construction Manager

Contract Administrator

Legal Counsel

Project Director

Commercial Manager

Quantity Surveyor

Project Manager

Chief Operating Officer

Procurement Manager

Risk Manager

Technical Director

Operations Manager

Claims Manager

Compliance Officer

Construction Director

Industries
UAE Federal Law No. 5 of 1985 (Civil Code): Primary legislation governing contracts, including specific provisions for construction contracts (Muqawala) in Articles 872-896, covering contractor obligations, employer rights, and project completion terms
UAE Federal Law No. 8 of 1980 (UAE Labor Law): Regulates employment relationships and working conditions, crucial for labor-related aspects of construction contracts including worker safety and rights
UAE Federal Law No. 18 of 1993 (Commercial Code): Governs commercial transactions and business relationships, relevant for commercial aspects of construction contracts
Dubai Local Order 3 of 1999: Dubai-specific construction regulations covering building permits, technical specifications, and construction standards
Abu Dhabi International Building Code: Comprehensive building regulations and standards specific to Abu Dhabi emirate
UAE Federal Law No. 24 of 1999 (Environmental Protection): Environmental regulations affecting construction projects, including environmental impact assessments and waste management
UAE Federal Law No. 6 of 2018 (Arbitration Law): Governs arbitration proceedings, crucial for dispute resolution clauses in construction contracts
UAE Cabinet Decision No. 31 of 2019 on Construction Health and Safety: Regulations specific to health and safety requirements in construction projects
Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Addendum Letter

find out more

Addendum For Extension Of Agreement

A UAE law-compliant document that extends the term of an existing agreement while maintaining or modifying its original terms.

find out more

Contract Amendment

find out more

Early Lease Termination Addendum

UAE-compliant addendum that formally documents the early termination of a lease agreement, including termination terms, settlements, and mutual releases.

find out more

Commercial Lease Addendum

A UAE-law governed document that modifies an existing commercial lease agreement, compliant with federal and emirate-specific property regulations.

find out more

Rental Pet Agreement

UAE-governed agreement for temporary pet rental arrangements, establishing care requirements and responsibilities while ensuring compliance with local animal welfare laws.

find out more

Pet Lease Agreement

UAE-governed agreement for temporary pet custody transfer, establishing care terms and responsibilities in compliance with local animal welfare laws.

find out more

Addendum To Consulting Agreement

UAE-governed document that modifies an existing consulting agreement, addressing changes in scope, fees, duration, or other material terms.

find out more

Construction Contract Addendum

UAE-compliant template for modifying existing construction contracts, incorporating local legal requirements and industry standards.

find out more

Addendum Loan Agreement

UAE-governed document modifying an existing loan agreement's terms and conditions, ensuring compliance with local laws and banking regulations.

find out more

Addendum To Service Agreement

A UAE law-governed document that modifies an existing Service Agreement, specifying changes while maintaining compliance with UAE Federal laws and Sharia principles.

find out more

Addendum To Rental Agreement

A UAE-compliant legal document that modifies an existing rental agreement, subject to Federal and emirate-specific property laws.

find out more

Addendum To Memorandum Of Agreement

A UAE-compliant legal document that modifies or supplements an existing memorandum of agreement, ensuring continued enforceability under UAE law.

find out more

Lease Addendum Change Of Ownership

A UAE-governed addendum that formally documents property ownership transfer while maintaining existing lease terms, ensuring compliance with UAE federal and emirate-specific property laws.

find out more

Furnished Apartment Lease Addendum

A UAE-compliant supplementary agreement to a main lease that specifies terms and conditions for furnished items in a residential rental property.

find out more

Employment Contract Addendum

UAE-compliant template for modifying existing employment contracts, designed to document changes to employment terms while ensuring legal compliance with UAE labor laws.

find out more

Contract Extension Addendum

A UAE law-governed document that extends an existing contract's duration while maintaining or modifying its original terms.

find out more

Pet Addendum For Lease

A UAE-compliant legal document that supplements a residential lease agreement by establishing terms and conditions for pet ownership in rental properties.

find out more

Lease Extension Addendum

A UAE-compliant addendum that extends an existing lease agreement while maintaining or updating its terms under relevant emirate-specific property laws.

find out more

Lease Amendment

UAE-compliant template for modifying existing lease agreements, incorporating federal and emirate-specific legal requirements.

find out more

Lease Amendment

A UAE law-governed document that modifies an existing lease agreement, requiring compliance with federal and emirate-specific property regulations.

find out more

Lease Addendum

UAE-compliant template for modifying existing lease agreements, ensuring alignment with local property laws and registration requirements.

find out more

Employment Contract Amendment

UAE-compliant template for modifying existing employment contracts, aligned with Federal Decree-Law No. 33 of 2021.

find out more

Contract Addendum

UAE-compliant template for modifying existing contracts through formal addendum, ensuring legal validity under UAE law.

find out more

Addendum To Employment Contract

A UAE-compliant document that modifies an existing employment contract, used to formally record changes to employment terms while adhering to UAE Labor Law.

find out more

Addendum To Agreement

A UAE law-compliant document that formally modifies an existing agreement, ensuring legal enforceability while maintaining the original contract's integrity.

find out more

Download our whitepaper on the future of AI in Legal

By providing your email address you are consenting to our Privacy Notice.
Thank you for downloading our whitepaper. This should arrive in your inbox shortly. In the meantime, why not jump straight to a section that interests you here: https://www.genieai.co/our-research
Oops! Something went wrong while submitting the form.

Genie’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; Genie’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

Our bank-grade security infrastructure undergoes regular external audits

We are ISO27001 certified, so your data is secure

Organizational security

You retain IP ownership of your documents

You have full control over your data and who gets to see it

Innovation in privacy:

Genie partnered with the Computational Privacy Department at Imperial College London

Together, we ran a £1 million research project on privacy and anonymity in legal contracts

Want to know more?

Visit our Trust Centre for more details and real-time security updates.

Read our Privacy Policy.