Owner Contractor Agreement Template for Singapore

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Owner Contractor Agreement

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Owner Contractor Agreement

"I need an Owner Contractor Agreement for a residential renovation project in Singapore valued at SGD 2.5M, with work starting in March 2025 and including specific provisions for sustainable materials and green building standards."

Document background

The Owner Contractor Agreement is a fundamental document in Singapore's construction industry, essential for any construction, renovation, or development project. It provides a legally binding framework that protects both the owner's and contractor's interests while ensuring compliance with Singapore's building codes and regulations. This agreement is particularly important as it defines project scope, payment terms, timelines, and quality standards, while incorporating requirements from the Building and Construction Authority (BCA) and relevant Singapore legislation. It's designed to prevent disputes through clear delineation of responsibilities and includes mechanisms for handling variations, delays, and dispute resolution.

Suggested Sections

1. Parties: Identifies and defines the Owner and Contractor with complete legal details

2. Background: Outlines the context and purpose of the agreement

3. Definitions: Defines key terms used throughout the agreement

4. Scope of Work: Detailed description of the works to be performed by the Contractor

5. Contract Sum and Payment Terms: Specifies the agreed price and payment schedule

6. Time for Completion: Specifies project timeline, milestones, and completion date

7. Contractor's Obligations: Lists all responsibilities and duties of the Contractor

8. Owner's Obligations: Lists all responsibilities and duties of the Owner

9. Insurance and Indemnity: Details required insurance coverage and indemnification provisions

10. Termination: Conditions and procedures for contract termination

Optional Sections

1. Performance Bond: Required when project value exceeds certain threshold or upon Owner's request

2. Liquidated Damages: Predetermined damages for delay or breach, typically used for time-sensitive projects

3. Variations: Procedures for handling changes to scope, recommended for complex projects likely to require changes

4. Defects Liability: Extended warranty period after completion, typically used for construction works requiring warranty

Suggested Schedules

1. Schedule 1 - Scope of Works: Detailed technical specifications and drawings

2. Schedule 2 - Payment Schedule: Detailed breakdown of payment milestones

3. Schedule 3 - Project Timeline: Detailed project schedule with milestones

4. Schedule 4 - Site Details: Site information and access details

5. Schedule 5 - Insurance Requirements: Detailed insurance specifications

6. Appendix A - Technical Drawings: Architectural and engineering drawings

7. Appendix B - Material Specifications: Detailed specifications of materials to be used

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Construction
Real Estate
Infrastructure
Industrial
Commercial

Relevant Teams

Legal
Operations
Procurement
Finance
Project Management Office
Risk Management
Compliance

Relevant Roles

Project Manager
Construction Manager
Property Developer
Contract Administrator
Quantity Surveyor
Legal Counsel
Risk Manager

Industries

Building Control Act: Primary legislation governing building works, structural requirements, and construction standards in Singapore

Building Control Regulations: Detailed regulations implementing the Building Control Act, specifying technical requirements and compliance standards

Building Maintenance and Strata Management Act: Legislation governing the maintenance of buildings and common property management

Contract Law of Singapore: Fundamental laws governing contract formation, execution, and enforcement in Singapore

Misrepresentation Act: Law dealing with false statements or misrepresentations made during contract formation

Electronic Transactions Act: Legislation governing electronic contracts and digital signatures

Employment Act: Core legislation governing employment terms and conditions in Singapore

Work Injury Compensation Act: Law providing compensation framework for work-related injuries and occupational diseases

Workplace Safety and Health Act: Legislation ensuring safety, health, and welfare of persons at workplaces

Employment of Foreign Manpower Act: Law regulating the employment of foreign workers in Singapore

Building and Construction Industry Security of Payment Act: Legislation facilitating payments for construction work and related goods and services

Environmental Protection and Management Act: Law governing environmental protection and pollution control in construction activities

Environmental Public Health Act: Legislation concerning public health aspects of construction and building maintenance

Professional Engineers Act: Law regulating professional engineering services and qualifications

Architects Act: Legislation governing architectural services and professional requirements

Arbitration Act: Law governing arbitration proceedings for dispute resolution

Mediation Act: Legislation framework for mediation as an alternative dispute resolution method

Insurance Act: Law regulating insurance requirements and coverage for construction projects

Land Titles Act: Legislation governing land ownership and property rights in Singapore

Planning Act: Law controlling land use and development in Singapore

Fire Safety Act: Legislation ensuring fire safety standards in buildings and construction

How a Sales & Marketing Lead uses Genie AI to reduce contract drafting time by 95%

Let's create your Owner Contractor Agreement

Authors

Alex Denne

Find the exact document you need

Subcontractor Service Agreement

Subcontractor Employment Agreement

Sole Trader Contract

Simple Subcontractor Contract

Simple Payment Agreement Contract

Residential Contractor Agreement

Pre Agreement Contract

Painting Contract Agreement

Independent Contractor And Non Compete

Foreign Independent Contractor Agreement

Driver Contractor Agreement

Domestic Subcontract Agreement

Contractor Service Agreement

Contractor Referral Agreement

Contract For Personal Service

Contract For Labor Agreement

Contract Between Employer And Independent Contractor

Consulting Agreement Contract

Construction Contractor Contract

Civil Work Contract Agreement

Subcontractor Hold Harmless Agreement

Salon Contract For Employees

Part Time Contractor Agreement

Mining Contractor Agreement

Home Remodel Contract

Framework Agreement Contract

Construction Warranty Agreement

Construction Service Contract

Contract Agreement Between Two Parties

Construction Contract Agreement Form

Binding Agreement Contract

Agreement Security Guard Contract

Agreement For Construction Of House

Agreement Between Contractor And Principal Employer

Independent Contractor Equity Agreement

Model Form Contract

Company Bond Contract

Construction Owner's Representative Contract

Profit Sharing Agreement Independent Contractor

Loan Officer Independent Contractor Agreement

Agreement Between Two Contractors

Security Guard Independent Contractor Agreement

Owner Contractor Agreement

Job Agreement Contract

Home Owners Contract

Cost Plus Contract Form

Contract For Commission Based Employment

Sale Agreement And Construction Agreement

Roofing Contract Agreement

Residential Contractor Contract

Independent Contractor Agreement Real Estate Salesperson

Indemnity Form For Contractors

Flooring Contract Agreement

Delivery Driver Contract Agreement

Employment Contract For Contract Workers

Construction Labor Contract Agreement

Residential Subcontractor Agreement

Temporary Contractor Agreement

Professional Agreement Contract

Exclusive Independent Contractor Agreement

Contract Of Employment Driver

Salesperson Independent Contractor Agreement

General Employment Contract

Driver Subcontractor Agreement

Agreement Contract Between Employer And Employees

Subcontractor Agreement For Professional Services

Short Subcontractor Agreement

Installation Contract Agreement

Independent Contractor Agreement Cleaning Services

Electrical Service Contract

Freelance Employee Contract

Builder Agreement

Party Agreement Contract

Marketing Contractor Agreement

Independent Contractor Hold Harmless Agreement