🖊️ Amendment agreement

The JCT Intermediate Building Contract - Schedule of Amendments under UK law is a legal template that outlines revisions and modifications made to the standard JCT Intermediate Building Contract. The JCT (Joint Contracts Tribunal) is a widely used suite of standard contracts in the UK construction industry, specifically formulated for construction and building projects.

This particular template, the Schedule of Amendments, is used when parties involved in a construction project wish to amend certain provisions of the standard JCT Intermediate Building Contract to better reflect their specific requirements and intentions. The template highlights the specific clauses and sections of the original contract that have been changed, deleted, or added, while providing clear and concise language to describe each amendment.

These amendments may include adjustments to payment terms, the scope of work, variations to the contract sum, extension of time provisions, dispute resolution procedures, and any other aspect of the contract that the parties deem necessary to modify.

By utilizing the JCT Intermediate Building Contract - Schedule of Amendments under UK law, the parties involved are able to accurately record and document any changes to the original contract, ensuring that all parties have a clear understanding of the revised terms and conditions. This template serves as a crucial legal tool to safeguard the interests of all stakeholders involved in the construction project, minimizing potential disputes or ambiguities that may arise due to the amendments made.

The JCT Design And Build Contract Amendments Schedule under UK law is a legal template that outlines the modification clauses and provisions for a construction agreement governed by the Joint Contracts Tribunal (JCT) guidelines. This schedule serves as an addendum to the original JCT Design And Build Contract, granting parties the ability to make specific changes to the terms, conditions, or specifications of the initial contract. The purpose of this template is to provide a comprehensive framework for parties involved in a construction project to document and implement amendments to the original contract while ensuring compliance with UK laws and regulations. It covers a wide range of possible modifications, including but not limited to changes in project scope, variations in pricing or payment terms, adjustments to project timelines, revisions in design or building specifications, and procedures for dispute resolution. This legal template aims to offer a clear and legally enforceable means for parties to modify their contractual obligations as necessitated by project-specific requirements, unforeseen circumstances, or evolving factors during the construction process.