All Templates
Provide collateral warranty
🏠 Collateral warranty
Sub-Contractor Collateral Warranty (Pro-Employer)
Sub-Contractor Collateral Warranty (Pro-Employer)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Provide collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
The legal template of the Sub-Contractor Collateral Warranty (Pro-Employer) under UK law is a comprehensive and standardized document that sets out the rights and obligations of a sub-contractor towards a third party employer in a construction project. This particular template is designed to heavily favor the employer's interests and offers additional protection to the employer in case of breach or negligence by the sub-contractor.
The document covers various aspects related to the sub-contractor's responsibilities, performance expectations, and potential liabilities in relation to the employer and any third parties directly affected by the construction project. It outlines the scope of work for the sub-contractor, specifying the tasks, timelines, quality standards, and any applicable regulations or industry standards that must be adhered to.
Additionally, the template ensures that the sub-contractor provides the necessary warranties, guarantees, and indemnities to the employer. These provisions serve to safeguard the employer against any financial losses, damages, or delays caused by the sub-contractor's actions or omissions. The template may also include details about insurance requirements, in order to ensure that both parties are adequately covered throughout the duration of the project.
Furthermore, this template may address dispute resolution mechanisms, such as arbitration or mediation, to resolve any conflicts that may arise between the sub-contractor and the employer. It may also specify the governing law and jurisdiction under which any legal disputes will be resolved, which in this case is UK law.
Overall, the Sub-Contractor Collateral Warranty (Pro-Employer) template emphasizes the employer's interests by establishing a clear framework of obligations and liabilities for the sub-contractor. By utilizing this legal document, both parties can have a comprehensive understanding of their respective roles and responsibilities, providing a foundation for a smoother and more transparent working relationship.
The document covers various aspects related to the sub-contractor's responsibilities, performance expectations, and potential liabilities in relation to the employer and any third parties directly affected by the construction project. It outlines the scope of work for the sub-contractor, specifying the tasks, timelines, quality standards, and any applicable regulations or industry standards that must be adhered to.
Additionally, the template ensures that the sub-contractor provides the necessary warranties, guarantees, and indemnities to the employer. These provisions serve to safeguard the employer against any financial losses, damages, or delays caused by the sub-contractor's actions or omissions. The template may also include details about insurance requirements, in order to ensure that both parties are adequately covered throughout the duration of the project.
Furthermore, this template may address dispute resolution mechanisms, such as arbitration or mediation, to resolve any conflicts that may arise between the sub-contractor and the employer. It may also specify the governing law and jurisdiction under which any legal disputes will be resolved, which in this case is UK law.
Overall, the Sub-Contractor Collateral Warranty (Pro-Employer) template emphasizes the employer's interests by establishing a clear framework of obligations and liabilities for the sub-contractor. By utilizing this legal document, both parties can have a comprehensive understanding of their respective roles and responsibilities, providing a foundation for a smoother and more transparent working relationship.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Time and Performance Based Employee Share Option Grant (Non Tax-Advantaged)
This legal template refers to a contractual agreement between an employer and an employee that grants the employee the option to purchase company shares at a predetermined price within a specified timeframe. The grant of these employee share options is specifically designed to incentivize and reward employees based on their performance and the length of their employment. This template is applicable in the United Kingdom and does not provide any tax advantages to the employee. It includes provisions outlining the terms and conditions of the share option grant, including the grant date, exercise price, vesting schedule, and any applicable restrictions or performance criteria. The template also includes provisions related to termination of employment and the treatment of unexercised share options in such cases. Overall, this legal template is intended to provide a framework for implementing a performance-based share option scheme for employees under UK law.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
2
DISCUSSIONS
2
TUPE Change of Employer Notice Due To Intra-group Reorganisation
This legal template pertains to the Transfer of Undertakings (Protection of Employment) Regulations 2006 (TUPE) in the United Kingdom. Specifically, it focuses on the process of notifying employees about a change of employer due to an intra-group reorganization.
An intra-group reorganization typically occurs when there is a restructuring within a group of companies, where businesses are moved or consolidated under a different legal entity within the same group. This template covers the legal requirements and necessary steps to inform affected employees about such an organizational change.
The template likely provides a framework for drafting a formal written notice to be sent to employees. It outlines the relevant details of the transfer, including the current employer, the proposed new employer, and the effective date of the transfer. Additionally, the template may address the employees' rights and protections under TUPE, ensuring that they are not disadvantaged by the transfer and their existing terms and conditions of employment are preserved.
This template serves as a practical tool for employers or legal professionals to comply with the legal obligations imposed by TUPE when informing employees of an intra-group reorganization. It helps ensure transparency, efficiency, and compliance throughout the transfer process, thereby safeguarding employees' rights and maintaining a smooth transition of employment.
An intra-group reorganization typically occurs when there is a restructuring within a group of companies, where businesses are moved or consolidated under a different legal entity within the same group. This template covers the legal requirements and necessary steps to inform affected employees about such an organizational change.
The template likely provides a framework for drafting a formal written notice to be sent to employees. It outlines the relevant details of the transfer, including the current employer, the proposed new employer, and the effective date of the transfer. Additionally, the template may address the employees' rights and protections under TUPE, ensuring that they are not disadvantaged by the transfer and their existing terms and conditions of employment are preserved.
This template serves as a practical tool for employers or legal professionals to comply with the legal obligations imposed by TUPE when informing employees of an intra-group reorganization. It helps ensure transparency, efficiency, and compliance throughout the transfer process, thereby safeguarding employees' rights and maintaining a smooth transition of employment.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
0
DISCUSSIONS
0
TUPE Employee Provisions for Asset Purchase Agreement
This legal template pertains to the Employee Provisions section of an Asset Purchase Agreement under UK law, specifically focusing on the Transfer of Undertakings (Protection of Employment) Regulations (TUPE). TUPE regulations aim to safeguard the rights and benefits of employees when their employer undergoes a change in ownership or a transfer of business assets. This template would outline the necessary provisions and obligations that both the buyer (the new employer) and the seller (the previous employer) must adhere to in order to comply with TUPE regulations. It would cover areas like employee transfer, continuity of employment, collective bargaining agreements, redundancy procedures, consultation requirements, employee rights and protections, and any other relevant aspects of the transfer process.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
2
RATINGS
0
DISCUSSIONS
1
