Sub-Contractor Collateral Warranty (Pro-Employer)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Provide collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
The document covers various aspects related to the sub-contractor's responsibilities, performance expectations, and potential liabilities in relation to the employer and any third parties directly affected by the construction project. It outlines the scope of work for the sub-contractor, specifying the tasks, timelines, quality standards, and any applicable regulations or industry standards that must be adhered to.
Additionally, the template ensures that the sub-contractor provides the necessary warranties, guarantees, and indemnities to the employer. These provisions serve to safeguard the employer against any financial losses, damages, or delays caused by the sub-contractor's actions or omissions. The template may also include details about insurance requirements, in order to ensure that both parties are adequately covered throughout the duration of the project.
Furthermore, this template may address dispute resolution mechanisms, such as arbitration or mediation, to resolve any conflicts that may arise between the sub-contractor and the employer. It may also specify the governing law and jurisdiction under which any legal disputes will be resolved, which in this case is UK law.
Overall, the Sub-Contractor Collateral Warranty (Pro-Employer) template emphasizes the employer's interests by establishing a clear framework of obligations and liabilities for the sub-contractor. By utilizing this legal document, both parties can have a comprehensive understanding of their respective roles and responsibilities, providing a foundation for a smoother and more transparent working relationship.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Witness Statement Supporting Application To Extend Administrator's Appointment
The witness statement may include information regarding the current state of affairs, the reason behind the need for an extension, the value and importance of the administrator's expertise in the specific case, as well as any positive impacts achieved during the initial appointment. The statement can also demonstrate the administrator's ongoing effectiveness in managing and resolving complex issues, maintaining stability, and safeguarding the interests of all relevant parties involved.
This template aims to present a persuasive case to the appropriate judicial or administrative authority, emphasizing the necessity and benefits of extending the administrator's appointment. By providing comprehensive details and concrete examples through the witness statement, it helps to build a compelling argument for the extension of the administrator's term, ultimately ensuring the continued success and smooth progression of the matter at hand.
Publisher
Genie AIJurisdiction
England and WalesVideo Editor Contract
This Video Editor contract template is designed for a commercial video editing organisation (or an individual video editor) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of video editing and video-editing-related services to be completed by the video editor on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the video editing firm or individual video editor on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
