All Templates
Sell or outsource software development
🧑💻 Software development agreement
Software Development Agreement (Pro-Supplier)
Software Development Agreement (Pro-Supplier)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useContract party
Relevant sectors
Type of legal document
🧑💻 Software development agreementBusiness activity
Sell or outsource software developmentA software development agreement is a contract between a software developer and a client that outlines the terms of the software development project. The agreement should include a description of the project, the roles and responsibilities of each party, the schedule and milestones, and the payment terms. The agreement should also address intellectual property ownership, confidentiality, and other legal issues.
The Software Development Agreement (Pro-Supplier) under UK law is a comprehensive legal template that governs the contractual relationship between a software development supplier and their client. This agreement sets out the terms and conditions that both parties must abide by throughout the software development process.
Primarily, this agreement focuses on protecting the rights and interests of the software development supplier. It outlines the scope of work, deliverables, and timelines agreed upon between the parties. The template also emphasizes intellectual property rights, stating that the supplier will retain ownership of any software developed unless otherwise agreed. It may include provisions for granting the client a license to use the software upon successful completion.
Additionally, the agreement addresses payment terms, including the amount and schedule of payments to be made by the client to the supplier. It may incorporate clauses to account for any change requests or additional work, establishing mechanisms to address such modifications to the original scope.
Confidentiality and data protection are paramount in this template, ensuring the supplier's trade secrets and the client's sensitive information remain secure. The agreement may impose obligations on both parties to maintain confidentiality and handle data in accordance with applicable laws and regulations.
Furthermore, the agreement may cover liability and indemnity provisions, allocating responsibility between the parties in the event of errors, delays, or breaches. It may include dispute resolution mechanisms such as mediation or arbitration, providing a structured process to address any conflicts that may arise.
Overall, the Software Development Agreement (Pro-Supplier) under UK law serves to establish a fair and balanced partnership between software development suppliers and their clients, ensuring both parties' interests are safeguarded while enabling the successful completion of software projects.
Primarily, this agreement focuses on protecting the rights and interests of the software development supplier. It outlines the scope of work, deliverables, and timelines agreed upon between the parties. The template also emphasizes intellectual property rights, stating that the supplier will retain ownership of any software developed unless otherwise agreed. It may include provisions for granting the client a license to use the software upon successful completion.
Additionally, the agreement addresses payment terms, including the amount and schedule of payments to be made by the client to the supplier. It may incorporate clauses to account for any change requests or additional work, establishing mechanisms to address such modifications to the original scope.
Confidentiality and data protection are paramount in this template, ensuring the supplier's trade secrets and the client's sensitive information remain secure. The agreement may impose obligations on both parties to maintain confidentiality and handle data in accordance with applicable laws and regulations.
Furthermore, the agreement may cover liability and indemnity provisions, allocating responsibility between the parties in the event of errors, delays, or breaches. It may include dispute resolution mechanisms such as mediation or arbitration, providing a structured process to address any conflicts that may arise.
Overall, the Software Development Agreement (Pro-Supplier) under UK law serves to establish a fair and balanced partnership between software development suppliers and their clients, ensuring both parties' interests are safeguarded while enabling the successful completion of software projects.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
UK Website Terms and Conditions (Terms of Use)
This legal template discusses the terms and conditions (also known as terms of use) that govern the use of a website in the United Kingdom. It outlines the contractual agreement between the website owner and the users, establishing the rights and obligations of both parties. The document covers various important aspects, including user consent, intellectual property rights, limitations of liability, privacy policy, dispute resolution, and applicable laws under UK jurisdiction. Compliance with UK legal requirements, such as the Consumer Rights Act 2015 and the General Data Protection Regulation (GDPR), may also be addressed. This legal template aims to protect the interests of both the website owner and the users by setting clear guidelines for the website's usage and ensuring compliance with relevant UK laws.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
1
DISCUSSIONS
1
Witness Statement of Truth Verifying Compulsory Liquidation
The Witness Statement of Truth Verifying Compulsory Liquidation under UK law is a legal template that outlines a written declaration made by a witness in relation to the process of compulsory liquidation in the United Kingdom. Compulsory liquidation refers to the legal procedure of winding up a company's affairs and distributing its assets by order of a court, typically due to the company's inability to pay its debts.
This template serves as a formal document that witnesses can use to confirm the accuracy and truthfulness of their statements regarding the company's liquidation proceedings. The statement includes relevant details such as the witness's personal information, their involvement or knowledge of the liquidation process, and a declaration that the information provided is true to the best of their knowledge.
By providing this Witness Statement of Truth, witnesses affirm their commitment to the legal obligations of their statements and acknowledge that any false information could result in legal consequences. This template aims to ensure transparency, integrity, and the proper administration of the compulsory liquidation process under UK law.
This template serves as a formal document that witnesses can use to confirm the accuracy and truthfulness of their statements regarding the company's liquidation proceedings. The statement includes relevant details such as the witness's personal information, their involvement or knowledge of the liquidation process, and a declaration that the information provided is true to the best of their knowledge.
By providing this Witness Statement of Truth, witnesses affirm their commitment to the legal obligations of their statements and acknowledge that any false information could result in legal consequences. This template aims to ensure transparency, integrity, and the proper administration of the compulsory liquidation process under UK law.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
2
RATINGS
2
DISCUSSIONS
0
Works Contractor Collateral Warranty (To Funder)
The Works Contractor Collateral Warranty (To Funder) under UK law is a legal template that establishes an agreement between a works contractor and a funder, typically in the construction industry. This template outlines the additional warranty provided by the works contractor to the funder, ensuring that the works contractor will fulfill the terms of the original contract and meet all contractual obligations.
The collateral warranty serves as a contractual document that underpins the contractual relationship between the funder and the works contractor. It safeguards the funder's interests by providing them with direct rights to enforce certain obligations and claims against the works contractor in case of any breaches, defects, or failures in meeting the contractual requirements.
The template outlines the specific terms and conditions of the collateral warranty, including the scope of obligations, limitations, and liabilities of the works contractor. It may also include provisions for dispute resolution, indemnity clauses, insurance requirements, and other relevant terms to protect the interests of both parties.
This legal document is crucial in ensuring that the funder's financial investment is protected by establishing a direct legal relationship with the works contractor, separate from the primary contract between the works contractor and the employer. It provides the funder with the necessary legal recourse and additional warranties directly from the works contractor, providing them with peace of mind in their financial support for the project or works being carried out.
Overall, the Works Contractor Collateral Warranty (To Funder) under UK law is a legal template that helps establish an agreement between the works contractor and the funder, safeguarding the funder's interests and ensuring that the works contractor fulfills their contractual obligations to the funder.
The collateral warranty serves as a contractual document that underpins the contractual relationship between the funder and the works contractor. It safeguards the funder's interests by providing them with direct rights to enforce certain obligations and claims against the works contractor in case of any breaches, defects, or failures in meeting the contractual requirements.
The template outlines the specific terms and conditions of the collateral warranty, including the scope of obligations, limitations, and liabilities of the works contractor. It may also include provisions for dispute resolution, indemnity clauses, insurance requirements, and other relevant terms to protect the interests of both parties.
This legal document is crucial in ensuring that the funder's financial investment is protected by establishing a direct legal relationship with the works contractor, separate from the primary contract between the works contractor and the employer. It provides the funder with the necessary legal recourse and additional warranties directly from the works contractor, providing them with peace of mind in their financial support for the project or works being carried out.
Overall, the Works Contractor Collateral Warranty (To Funder) under UK law is a legal template that helps establish an agreement between the works contractor and the funder, safeguarding the funder's interests and ensuring that the works contractor fulfills their contractual obligations to the funder.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
2
DISCUSSIONS
1
