Pay Less Notice (Construction Contract)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Pay less noticeBusiness activity
Pay less noticeThe Pay Less Notice (Construction Contract) is a legal template commonly used in the United Kingdom within the construction industry. This document serves as a formal notice to the contractor from the employer, highlighting the intention to pay an amount less than the sum usually invoiced for the completed work or ongoing project.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
How it works
Create doc / use template
Chat to our AI Legal Assistant
Edit, collaborate & share
Export to .docx
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Trade Mark Infiringement And Passing Off (Particulars Of Claim)
This legal template relates to a legal action filed in the United Kingdom under the Trade Mark Infringement and Passing Off laws for the potential violation of someone's intellectual property rights. The template is specifically designed for filing the "Particulars of Claim" document, which outlines the details and allegations of the case.
In a trade mark infringement case, the claimant (the party bringing the action) asserts that their registered trademark has been unlawfully used by the defendant (the party being accused). This could involve unauthorized use of their brand name, logo, or any other distinctive sign that uniquely identifies their goods or services, causing confusion among consumers and potentially impacting the claimant's reputation or business.
Simultaneously, passing off refers to a situation where the defendant misrepresents their goods or services as those of the claimant, leading consumers to believe they are purchasing products connected to or endorsed by the claimant. Passing off can occur even without a registered trademark, as long as the claimant can demonstrate that they have built up a reputation and goodwill around their brand that the defendant is attempting to exploit.
This legal template provides a structured framework for the claimant to state their case by precisely outlining the circumstances of the infringement and passing off, including descriptions of the trade mark(s) infringing, relevant dates, locations, the defendant's actions, and any damages suffered by the claimant. By following this template, the claimant can ensure that they provide all the necessary details to present a compelling case before the courts, seeking remedies such as injunctions, damages, or an account of profits.
It's important to note that this description is a general overview and serves as an introduction to the legal template. The specific contents and requirements of the template may vary depending on the unique circumstances of each case, as well as the applicable laws and regulations in the United Kingdom. Consulting with a legal professional is strongly advised to tailor the template to the specific case requirements and ensure compliance with relevant legal standards.
In a trade mark infringement case, the claimant (the party bringing the action) asserts that their registered trademark has been unlawfully used by the defendant (the party being accused). This could involve unauthorized use of their brand name, logo, or any other distinctive sign that uniquely identifies their goods or services, causing confusion among consumers and potentially impacting the claimant's reputation or business.
Simultaneously, passing off refers to a situation where the defendant misrepresents their goods or services as those of the claimant, leading consumers to believe they are purchasing products connected to or endorsed by the claimant. Passing off can occur even without a registered trademark, as long as the claimant can demonstrate that they have built up a reputation and goodwill around their brand that the defendant is attempting to exploit.
This legal template provides a structured framework for the claimant to state their case by precisely outlining the circumstances of the infringement and passing off, including descriptions of the trade mark(s) infringing, relevant dates, locations, the defendant's actions, and any damages suffered by the claimant. By following this template, the claimant can ensure that they provide all the necessary details to present a compelling case before the courts, seeking remedies such as injunctions, damages, or an account of profits.
It's important to note that this description is a general overview and serves as an introduction to the legal template. The specific contents and requirements of the template may vary depending on the unique circumstances of each case, as well as the applicable laws and regulations in the United Kingdom. Consulting with a legal professional is strongly advised to tailor the template to the specific case requirements and ensure compliance with relevant legal standards.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
2
RATINGS
3
DISCUSSIONS
0
Test Engineer Contract
This Test Engineer contract template is designed for a commercial testing organisation (or an individual test engineer) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of testing and testing-related services to be completed by the test engineer on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the testing firm or individual test engineer on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
6
RATINGS
1
DISCUSSIONS
0
Standard Resolution To Approve A Small Loan To A Director (Board Minutes)
This legal template outlines the standard resolution that can be used by a company's board of directors to approve a small loan granted to one of its directors under UK law. The document serves as a record of the board's decision-making process and ensures compliance with applicable laws and regulations.
The template includes sections specifying the details of the loan, such as the amount, interest rate, repayment terms, and purpose of the loan. It also outlines any specific conditions or requirements that need to be met by the director. Additionally, the template may include provisions for any necessary shareholder approval or disclosure obligations that may arise from granting the loan.
By utilizing this template, the company's board can clearly document the decision to approve the loan and demonstrate adherence to legal and fiduciary responsibilities. The standardized format ensures that all necessary information is adequately captured, creating a transparent and well-documented resolution.
It is important to note that while this template provides a framework for the resolution, it is highly recommended to consult with a qualified legal professional to tailor the document to the specific circumstances and ensure compliance with any company-specific bylaws or articles of association, as well as any relevant financial regulations applicable to the specific company or director.
The template includes sections specifying the details of the loan, such as the amount, interest rate, repayment terms, and purpose of the loan. It also outlines any specific conditions or requirements that need to be met by the director. Additionally, the template may include provisions for any necessary shareholder approval or disclosure obligations that may arise from granting the loan.
By utilizing this template, the company's board can clearly document the decision to approve the loan and demonstrate adherence to legal and fiduciary responsibilities. The standardized format ensures that all necessary information is adequately captured, creating a transparent and well-documented resolution.
It is important to note that while this template provides a framework for the resolution, it is highly recommended to consult with a qualified legal professional to tailor the document to the specific circumstances and ensure compliance with any company-specific bylaws or articles of association, as well as any relevant financial regulations applicable to the specific company or director.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
6
RATINGS
4
DISCUSSIONS
2
