Pay Less Notice (Construction Contract)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Pay less noticeBusiness activity
Pay less noticeA pay less notice is a notice served by a contractor to a sub-contractor that sets out the sum the contractor considers to be due under the sub-contract. The notice must be served before the final date for payment stated in the sub-contract. If the sub-contractor does not agree with the sum stated in the pay less notice, they can serve a notice of intention to withhold payment.
The Pay Less Notice (Construction Contract) is a legal template commonly used in the United Kingdom within the construction industry. This document serves as a formal notice to the contractor from the employer, highlighting the intention to pay an amount less than the sum usually invoiced for the completed work or ongoing project.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
SME ICT Policy
This legal template pertains to the Small and Medium-sized Enterprises (SME) Information and Communication Technology (ICT) Policy in the United Kingdom (UK). This document provides a comprehensive framework for SMEs operating within the UK to establish and enforce policies pertaining to ICT usage within their organization.
The template outlines the legal obligations, rights, and best practices that SMEs should adhere to regarding the acquisition, usage, management, and security of ICT assets, systems, and networks. It incorporates relevant UK laws and regulations, including data protection, privacy, cybersecurity, intellectual property, and electronic communications regulations, to ensure compliance with the legal requirements specific to the UK ICT landscape.
This template covers a wide range of topics, including but not limited to employee ICT usage guidelines, acceptable use policies for company-owned devices, protection of sensitive data and intellectual property, data and network security protocols, incident response and reporting, ICT procurement and vendor management, remote working policies, and compliance with industry standards.
Specifically tailored to SMEs, this legal template offers guidance for organizations with limited resources and provides practical measures to ensure the effective and lawful usage of ICT systems while minimizing legal risks and protecting the interests of the company, its employees, and its stakeholders.
The template outlines the legal obligations, rights, and best practices that SMEs should adhere to regarding the acquisition, usage, management, and security of ICT assets, systems, and networks. It incorporates relevant UK laws and regulations, including data protection, privacy, cybersecurity, intellectual property, and electronic communications regulations, to ensure compliance with the legal requirements specific to the UK ICT landscape.
This template covers a wide range of topics, including but not limited to employee ICT usage guidelines, acceptable use policies for company-owned devices, protection of sensitive data and intellectual property, data and network security protocols, incident response and reporting, ICT procurement and vendor management, remote working policies, and compliance with industry standards.
Specifically tailored to SMEs, this legal template offers guidance for organizations with limited resources and provides practical measures to ensure the effective and lawful usage of ICT systems while minimizing legal risks and protecting the interests of the company, its employees, and its stakeholders.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
3
DISCUSSIONS
2
SME Whistleblower Policy And Procedure
The SME Whistleblower Policy and Procedure under UK law is a legal template specifically designed for small and medium-sized enterprises (SMEs) operating within the United Kingdom. This comprehensive document outlines the guidelines and procedures that an SME must adhere to when handling internal whistleblowing cases.
The template begins by providing a clear definition of whistleblowing and the importance of creating a safe and secure environment for employees to report any wrongdoing or illegal activities they encounter within the organization. It emphasizes the significance of protecting whistleblowers from retaliation or victimization, ensuring their confidentiality, and encouraging open communication.
The policy then outlines the step-by-step procedure that an SME should follow when handling a whistleblowing complaint. It includes details on how employees should report their concerns, who the designated whistleblowing contact person is, and the process for investigating and resolving cases. The template also addresses the responsibility of management in supporting and supervising the procedure, ensuring fair treatment for all parties involved, and taking appropriate disciplinary actions, if necessary.
Moreover, the document provides guidance on how to maintain accurate records of all whistleblowing cases and the importance of assessing the effectiveness of the policy periodically. It also highlights the legal protections available to whistleblowers under UK law, such as the Public Interest Disclosure Act (PIDA) and Employment Rights Act, emphasizing the SME's commitment to complying with these statutes.
Overall, the SME Whistleblower Policy and Procedure under UK law serves as a crucial tool for SMEs in maintaining a transparent and ethical work environment. By establishing clear guidelines, it enables organizations to handle whistleblowing complaints effectively, protect the rights of employees, and prevent potential legal and reputational risks that may arise from internal misconduct.
The template begins by providing a clear definition of whistleblowing and the importance of creating a safe and secure environment for employees to report any wrongdoing or illegal activities they encounter within the organization. It emphasizes the significance of protecting whistleblowers from retaliation or victimization, ensuring their confidentiality, and encouraging open communication.
The policy then outlines the step-by-step procedure that an SME should follow when handling a whistleblowing complaint. It includes details on how employees should report their concerns, who the designated whistleblowing contact person is, and the process for investigating and resolving cases. The template also addresses the responsibility of management in supporting and supervising the procedure, ensuring fair treatment for all parties involved, and taking appropriate disciplinary actions, if necessary.
Moreover, the document provides guidance on how to maintain accurate records of all whistleblowing cases and the importance of assessing the effectiveness of the policy periodically. It also highlights the legal protections available to whistleblowers under UK law, such as the Public Interest Disclosure Act (PIDA) and Employment Rights Act, emphasizing the SME's commitment to complying with these statutes.
Overall, the SME Whistleblower Policy and Procedure under UK law serves as a crucial tool for SMEs in maintaining a transparent and ethical work environment. By establishing clear guidelines, it enables organizations to handle whistleblowing complaints effectively, protect the rights of employees, and prevent potential legal and reputational risks that may arise from internal misconduct.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
1
RATINGS
1
DISCUSSIONS
1
Standard Advice To Prepare A Witness Statement For The Employment Tribunal (Letter To A Witness)
This legal template, "Standard Advice to Prepare a Witness Statement for the Employment Tribunal (Letter to a Witness)," is designed to provide guidance and instructions to an individual who has been called upon as a witness in an employment tribunal case in the United Kingdom (UK). The template aims to assist the recipient in preparing a comprehensive and accurate witness statement, ensuring they understand their responsibilities and the necessary steps involved in providing evidence.
The template would likely include information related to the witness's obligations, such as the importance of providing truthful and honest testimony, the significance of their role in assisting the tribunal in making a fair and informed decision, and the potential consequences of providing misleading or incomplete information.
Furthermore, the template may offer detailed advice on how to structure and present their witness statement effectively. This could involve providing guidance on including relevant details, events, dates, and individuals involved, as well as emphasizing the importance of clarity, objectivity, and organization in their statement. The template may also outline the recommended format, language, and tone to be used in the witness statement.
Additionally, the template might address potential challenges or strategies that the witness might need to consider during cross-examination, offering guidance on how to remain composed, focused, and responsive in order to present their evidence convincingly.
Overall, this legal template serves as a valuable resource that provides a witness with guidance and instructions to enable them to prepare a well-structured, accurate, and persuasive witness statement for an employment tribunal in compliance with UK law.
The template would likely include information related to the witness's obligations, such as the importance of providing truthful and honest testimony, the significance of their role in assisting the tribunal in making a fair and informed decision, and the potential consequences of providing misleading or incomplete information.
Furthermore, the template may offer detailed advice on how to structure and present their witness statement effectively. This could involve providing guidance on including relevant details, events, dates, and individuals involved, as well as emphasizing the importance of clarity, objectivity, and organization in their statement. The template may also outline the recommended format, language, and tone to be used in the witness statement.
Additionally, the template might address potential challenges or strategies that the witness might need to consider during cross-examination, offering guidance on how to remain composed, focused, and responsive in order to present their evidence convincingly.
Overall, this legal template serves as a valuable resource that provides a witness with guidance and instructions to enable them to prepare a well-structured, accurate, and persuasive witness statement for an employment tribunal in compliance with UK law.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
9
RATINGS
2
DISCUSSIONS
0
