All Templates
Carry out works
⛪ Licence to carry out works
Licence To Carry Out Works (Landlord Giving Consent)
Licence To Carry Out Works (Landlord Giving Consent)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
⛪ Licence to carry out worksBusiness activity
Carry out worksThe License to Carry Out Works (Landlord Giving Consent) template is a legally binding document designed for use in the United Kingdom. This template outlines the consent given by a landlord to a tenant or another party, allowing them to carry out specific works or alterations on a property under the landlord's ownership.
The purpose of this template is to provide a formal agreement between the landlord and the party undertaking the works, ensuring that both parties have a clear understanding of their respective responsibilities and obligations. It establishes the terms and conditions under which the consent is given, including any restrictions or limitations on the type, scope, or duration of the proposed works.
This license document serves to protect the interests of the landlord, ensuring that the property is not subject to unauthorized or potentially damaging alterations. It enables the landlord to maintain control over their property and ensures that the works carried out comply with legal and regulatory requirements.
Key components included in this document typically cover details such as:
1. Identifying the parties involved: The template will require clarification of the landlord's and the tenant's or party carrying out the works' names and contact information. It may also include details regarding the property's address and description.
2. Defining the works: The license will outline the specific works that have been authorized, detailing what is permitted and what is not allowed. This can include, for instance, renovations, refurbishments, installations, or other alterations.
3. Duration: The agreed-upon time period during which the license to carry out works is valid will be clearly stated in the template. This ensures that the tenant or authorized party completes the works within the agreed timeframe.
4. Insurance and liabilities: The document may outline the insurance requirements, specifying the necessary coverage for the works being carried out. It may also allocate responsibilities for any damages, losses, or accidents related to the works.
5. Compliance with laws and regulations: The template will emphasize the need for the works to comply with all applicable laws, building regulations, planning permissions, and other legal obligations.
6. Security of the property: The license may include provisions for security, access control, and safeguarding the property during the works, specifying measures to protect the landlord's interests.
By utilizing this legal template, landlords can ensure that their property is protected while providing consent for necessary or desired works to be carried out. Similarly, it offers tenants or authorized parties a formal agreement, promoting clarity and understanding of their rights and obligations.
The purpose of this template is to provide a formal agreement between the landlord and the party undertaking the works, ensuring that both parties have a clear understanding of their respective responsibilities and obligations. It establishes the terms and conditions under which the consent is given, including any restrictions or limitations on the type, scope, or duration of the proposed works.
This license document serves to protect the interests of the landlord, ensuring that the property is not subject to unauthorized or potentially damaging alterations. It enables the landlord to maintain control over their property and ensures that the works carried out comply with legal and regulatory requirements.
Key components included in this document typically cover details such as:
1. Identifying the parties involved: The template will require clarification of the landlord's and the tenant's or party carrying out the works' names and contact information. It may also include details regarding the property's address and description.
2. Defining the works: The license will outline the specific works that have been authorized, detailing what is permitted and what is not allowed. This can include, for instance, renovations, refurbishments, installations, or other alterations.
3. Duration: The agreed-upon time period during which the license to carry out works is valid will be clearly stated in the template. This ensures that the tenant or authorized party completes the works within the agreed timeframe.
4. Insurance and liabilities: The document may outline the insurance requirements, specifying the necessary coverage for the works being carried out. It may also allocate responsibilities for any damages, losses, or accidents related to the works.
5. Compliance with laws and regulations: The template will emphasize the need for the works to comply with all applicable laws, building regulations, planning permissions, and other legal obligations.
6. Security of the property: The license may include provisions for security, access control, and safeguarding the property during the works, specifying measures to protect the landlord's interests.
By utilizing this legal template, landlords can ensure that their property is protected while providing consent for necessary or desired works to be carried out. Similarly, it offers tenants or authorized parties a formal agreement, promoting clarity and understanding of their rights and obligations.
How it works
Create doc / use template
Chat to our AI Legal Assistant
Edit, collaborate & share
Export to .docx
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Witness Statement Supporting Application Of Enforcement of Adjudication
This legal template is designed to assist individuals or businesses applying for the enforcement of an adjudication decision under UK law. An adjudication decision is a binding decision made by an adjudicator, typically appointed to resolve disputes related to construction projects or other contractual matters.
The template provides a structure for a witness statement, which is a written account of facts and evidence that a witness must provide to support the application for enforcement. This statement typically outlines the witness's knowledge, involvement, or observations related to the dispute and the adjudication process.
The purpose of this template is to ensure that the witness statement is organized, comprehensive, and aligned with the requirements set forth by UK law. It may include sections to summarize the witness's background, their relationship with the parties involved, detailed chronology of events leading to the dispute, and specific details about the adjudication procedure, including any relevant documents or correspondence.
By using this template, applicants can provide a well-structured witness statement that strengthens their case for the enforcement of the adjudication decision. It helps maintain consistency and clarity in the legal document, thereby increasing the chance of a successful outcome in the enforcement proceedings.
The template provides a structure for a witness statement, which is a written account of facts and evidence that a witness must provide to support the application for enforcement. This statement typically outlines the witness's knowledge, involvement, or observations related to the dispute and the adjudication process.
The purpose of this template is to ensure that the witness statement is organized, comprehensive, and aligned with the requirements set forth by UK law. It may include sections to summarize the witness's background, their relationship with the parties involved, detailed chronology of events leading to the dispute, and specific details about the adjudication procedure, including any relevant documents or correspondence.
By using this template, applicants can provide a well-structured witness statement that strengthens their case for the enforcement of the adjudication decision. It helps maintain consistency and clarity in the legal document, thereby increasing the chance of a successful outcome in the enforcement proceedings.
Read More
Publisher
Genie AIJurisdiction
England and Wales
Withholding Notice (Construction Contract)
The Withholding Notice (Construction Contract) legal template under UK law is a document used in the construction industry to provide formal notification of withholding payment to a contractor or subcontractor. This template is typically utilized when there are legitimate concerns or disputes regarding the quality of work, completion delays, breach of contract, or any other contractual issues that justify withholding payment.
The template outlines the relevant details such as project information, parties involved, and the specific reasons for withholding payment. It incorporates the necessary legal language and provisions required by UK law to ensure compliance and protection of both parties' rights. Additionally, it may include the amount being withheld, the date the notice is being issued, and any applicable deadlines for rectifying the mentioned issues.
By using this template, it allows the withholding party to communicate their concerns clearly and formally to the contractor, highlighting any breach or non-compliance that has occurred under the construction contract. This document serves as a vital tool in resolving disputes and initiating discussions for potential resolution prior to progressing to more formal legal actions or arbitration.
It is important to note that the Withholding Notice (Construction Contract) template under UK law should be reviewed by legal professionals who are specialized in construction law or litigation to ensure its suitability and compliance with the specific circumstances and jurisdiction.
The template outlines the relevant details such as project information, parties involved, and the specific reasons for withholding payment. It incorporates the necessary legal language and provisions required by UK law to ensure compliance and protection of both parties' rights. Additionally, it may include the amount being withheld, the date the notice is being issued, and any applicable deadlines for rectifying the mentioned issues.
By using this template, it allows the withholding party to communicate their concerns clearly and formally to the contractor, highlighting any breach or non-compliance that has occurred under the construction contract. This document serves as a vital tool in resolving disputes and initiating discussions for potential resolution prior to progressing to more formal legal actions or arbitration.
It is important to note that the Withholding Notice (Construction Contract) template under UK law should be reviewed by legal professionals who are specialized in construction law or litigation to ensure its suitability and compliance with the specific circumstances and jurisdiction.
Read More
Publisher
Genie AIJurisdiction
England and WalesWitness Statement In Opposition To Summary Judgment Application
This legal template is a document that allows an individual, often referred to as the witness, to provide their statement and arguments opposing a summary judgment application under UK law. Summary judgment is a legal procedure used to promptly resolve a case by determining whether there is any genuine issue to be tried or if the opposing party has a valid defense or claim. In this template, the witness can outline their evidence, arguments, and any relevant facts that support their opposition to the summary judgment application. The template is tailored specifically for the legal system in the United Kingdom and aims to assist individuals in presenting a comprehensive and compelling case against the granting of summary judgment.
Read More
Publisher
Genie AIJurisdiction
England and Wales