All Templates
Amend JCT contract
🔖 JCT building contract
JCT Standard Building Contract Amendments Schedule
JCT Standard Building Contract Amendments Schedule
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🔖 JCT building contractBusiness activity
Amend JCT contractA jct building contract is a contract between a builder and a client that sets out the terms and conditions under which the builder will carry out building work. The contract will cover matters such as the price, the scope of work, the schedule of work, and the terms and conditions under which the work will be carried out. The contract will also set out the rights and responsibilities of both parties, and will provide a mechanism for resolving disputes.
The JCT Standard Building Contract Amendments Schedule under UK law is a legal template that outlines the modifications and additions to the JCT Standard Building Contract, which is widely used in the construction industry in the United Kingdom. This document serves as an essential tool for parties involved in construction projects, including contractors, subcontractors, employers, and consultants, to amend the terms and conditions of the standard contract to suit the specific requirements of their project.
The template provides a systematic framework for making changes, additions, or deletions to the original JCT Standard Building Contract. These modifications may include alterations to key provisions, such as payment terms, completion dates, design liability, insurance requirements, dispute resolution mechanisms, and many other aspects of the construction agreement. The amendments schedule ensures clarity, consistency, and legal validity of the contract changes, thus protecting the rights and interests of all parties involved in the project.
By utilizing this legal template, construction professionals can tailor the JCT Standard Building Contract to meet the unique specifications and circumstances of their particular project, providing greater flexibility and clarity in the contractual relationship. It allows parties to address specific project requirements, unforeseen circumstances, or changes in legislation, while adhering to legal standards and obligations set forth by UK law.
Overall, the JCT Standard Building Contract Amendments Schedule under UK law plays a critical role in supporting efficient, fair, and transparent contract administration within the construction industry. It ensures that all parties are aware of and agree upon modifications to the original standard contract, mitigating potential conflicts, and contributing to successful project delivery.
The template provides a systematic framework for making changes, additions, or deletions to the original JCT Standard Building Contract. These modifications may include alterations to key provisions, such as payment terms, completion dates, design liability, insurance requirements, dispute resolution mechanisms, and many other aspects of the construction agreement. The amendments schedule ensures clarity, consistency, and legal validity of the contract changes, thus protecting the rights and interests of all parties involved in the project.
By utilizing this legal template, construction professionals can tailor the JCT Standard Building Contract to meet the unique specifications and circumstances of their particular project, providing greater flexibility and clarity in the contractual relationship. It allows parties to address specific project requirements, unforeseen circumstances, or changes in legislation, while adhering to legal standards and obligations set forth by UK law.
Overall, the JCT Standard Building Contract Amendments Schedule under UK law plays a critical role in supporting efficient, fair, and transparent contract administration within the construction industry. It ensures that all parties are aware of and agree upon modifications to the original standard contract, mitigating potential conflicts, and contributing to successful project delivery.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Witness Statement In Support Of Summary Judgment Application
This legal template would likely be a document used in the legal proceedings of a case in the United Kingdom. Specifically, it would be utilized as a witness statement prepared in support of a summary judgment application.
A summary judgment application is a legal procedure wherein one party involved in a lawsuit seeks to obtain a judgment in their favor without going through a full trial. This is typically pursued when the party believes that the case lacks merit or that there are no genuine issues in dispute that would necessitate a trial.
The purpose of this witness statement template would be to allow a witness to present relevant facts, evidence, and testimonies in support of the summary judgment application. The statement could include details about what the witness observed, heard, or experienced relevant to the case. The witness might elaborate on their relationship to the parties involved, any documents or records they possess that are related to the case, or any other relevant information they can provide.
This template would likely provide a structured format to guide witnesses in organizing their statements. It may include sections such as an introduction identifying the witness and their relationship to the case, a summary of the facts and issues in dispute, a detailed account of events, the witness's understanding of key legal principles, supporting evidence, and a conclusion summarizing their position.
Overall, this witness statement template would serve as a crucial resource for individuals involved in legal proceedings in the UK who are seeking to present robust evidence and arguments in support of a summary judgment application.
A summary judgment application is a legal procedure wherein one party involved in a lawsuit seeks to obtain a judgment in their favor without going through a full trial. This is typically pursued when the party believes that the case lacks merit or that there are no genuine issues in dispute that would necessitate a trial.
The purpose of this witness statement template would be to allow a witness to present relevant facts, evidence, and testimonies in support of the summary judgment application. The statement could include details about what the witness observed, heard, or experienced relevant to the case. The witness might elaborate on their relationship to the parties involved, any documents or records they possess that are related to the case, or any other relevant information they can provide.
This template would likely provide a structured format to guide witnesses in organizing their statements. It may include sections such as an introduction identifying the witness and their relationship to the case, a summary of the facts and issues in dispute, a detailed account of events, the witness's understanding of key legal principles, supporting evidence, and a conclusion summarizing their position.
Overall, this witness statement template would serve as a crucial resource for individuals involved in legal proceedings in the UK who are seeking to present robust evidence and arguments in support of a summary judgment application.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
1
DISCUSSIONS
2
Vesting Certificate (Construction)
The Vesting Certificate (Construction) is a legal template specific to UK law that pertains to the transfer of ownership rights from one party to another within the context of a construction project. This certificate is commonly used in situations where the employer/client intends to grant ownership of certain assets or property to the contractor or subcontractor upon completion of specific milestones or stages of the construction project.
The template typically includes essential information such as the names and addresses of both the employer and the contractor, a detailed description of the assets or property being vested, and the specific conditions and criteria that need to be met for the transfer of ownership to take place. It may further outline the payment terms, deadlines, and penalties associated with the vesting process.
Moreover, the Vesting Certificate (Construction) may encompass provisions related to unresolved disputes or discrepancies between the parties involved, as well as mechanisms for the termination or variation of the vesting agreement. This document serves as an important legal instrument to ensure transparency, fairness, and compliance throughout the construction project, providing a clear framework for the transfer of ownership rights from the employer to the contractor in accordance with UK law.
The template typically includes essential information such as the names and addresses of both the employer and the contractor, a detailed description of the assets or property being vested, and the specific conditions and criteria that need to be met for the transfer of ownership to take place. It may further outline the payment terms, deadlines, and penalties associated with the vesting process.
Moreover, the Vesting Certificate (Construction) may encompass provisions related to unresolved disputes or discrepancies between the parties involved, as well as mechanisms for the termination or variation of the vesting agreement. This document serves as an important legal instrument to ensure transparency, fairness, and compliance throughout the construction project, providing a clear framework for the transfer of ownership rights from the employer to the contractor in accordance with UK law.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
0
DISCUSSIONS
1
UK Tax Section For Stand-Alone Corporate Bond Issue Circular
This legal template likely refers to a document related to the issuance of corporate bonds under UK law. The template is specifically tailored to outline the taxation aspects associated with a stand-alone corporate bond issue in the UK. It could provide detailed information on various tax considerations, obligations, and regulations applicable to both the issuer and investors involved in the corporate bond issuance. The template might cover topics like tax implications of interest payments, withholding taxes, capital gains tax, stamp duty, tax exemptions or reliefs, and any specific tax requirements or provisions under UK legislation. By utilizing this template, issuers and investors can ensure compliance with relevant tax regulations and make informed decisions regarding the issuance or investment in a stand-alone corporate bond in the UK.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
3
RATINGS
2
DISCUSSIONS
2
