JCT Intermediate Building Contract - Schedule Of Amendments
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🖊️ Amendment agreementBusiness activity
Amend JCT contractAn amendment agreement is a document that is used to make changes to an existing contract. The amendment agreement will list the changes that are being made and the parties that are agreeing to the changes. The amendment agreement will need to be signed by both parties in order to be valid.
This particular template, the Schedule of Amendments, is used when parties involved in a construction project wish to amend certain provisions of the standard JCT Intermediate Building Contract to better reflect their specific requirements and intentions. The template highlights the specific clauses and sections of the original contract that have been changed, deleted, or added, while providing clear and concise language to describe each amendment.
These amendments may include adjustments to payment terms, the scope of work, variations to the contract sum, extension of time provisions, dispute resolution procedures, and any other aspect of the contract that the parties deem necessary to modify.
By utilizing the JCT Intermediate Building Contract - Schedule of Amendments under UK law, the parties involved are able to accurately record and document any changes to the original contract, ensuring that all parties have a clear understanding of the revised terms and conditions. This template serves as a crucial legal tool to safeguard the interests of all stakeholders involved in the construction project, minimizing potential disputes or ambiguities that may arise due to the amendments made.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Site Manager Contract
This Site Manager contract template is designed for a commercial site management organisation (or an individual site manager) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of site management and site-management-related services to be completed by the site manager on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the site management firm or individual site manager on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
Publisher
Genie AIJurisdiction
England and WalesStandard Application Notice to Court (Company Administration)
Company administration is a legal process that involves appointing an insolvency practitioner to take control of a financially troubled company's affairs. By submitting this Standard Application Notice to Court, the company seeks to gain court approval to enter administration, which is aimed at protecting the interests of the company's creditors and stakeholders while exploring options for possible recovery or restructuring.
The template typically includes crucial details such as the name and address of the company, a summary of the company's financial position, the reasons for seeking administration, and the proposed administrator's information. It may also outline any potential adverse effects that could arise from delaying or denying the administration request, emphasizing the urgency of court intervention.
This legal document plays a vital role in initiating the company administration process within the confines of UK law. It ensures that all necessary information is provided to the court, helping to establish a transparent and fair process for all parties involved.
