JCT Construction Management Appointment
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏠 Construction management agreementBusiness activity
Appoint construction managerA construction management agreement is a contract between a property owner and a construction manager. The agreement outlines the construction manager's duties, which include coordinating and supervising the construction work, and the property owner's responsibilities, which include providing the construction manager with the necessary resources. The agreement also establishes the terms under which the construction manager will be compensated.
This legal template ensures that all parties involved in the construction project, including the employer, contractor, and construction manager, have a clear understanding of their respective roles and obligations. It sets out the rights and obligations of the construction manager, including their duties to manage and coordinate the construction works, oversee subcontractors, and ensure compliance with relevant laws, regulations, and industry standards.
The template underlines the construction manager's responsibilities in terms of health and safety, quality control, procurement, as well as providing regular updates and progress reports to the employer. It typically includes provisions for dealing with delays, variations, and financial claims, helping to establish a fair and transparent payment mechanism between the employer and the construction manager.
Additionally, the template specifies the mechanism for dispute resolution, potentially including arbitration, mediation, or adjudication clauses, providing a framework to handle any disagreements or conflicts that may arise during the project.
Overall, the JCT Construction Management Appointment under UK Law legal template is a comprehensive and standardized document that aids in establishing a clear contractual relationship between the employer and the construction manager, ensuring compliance with UK construction regulations, and promoting successful completion of the construction project.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Site Manager Contract
This Site Manager contract template is designed for a commercial site management organisation (or an individual site manager) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of site management and site-management-related services to be completed by the site manager on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the site management firm or individual site manager on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
Publisher
Genie AIJurisdiction
England and WalesStandard Application Notice to Court (Company Administration)
Company administration is a legal process that involves appointing an insolvency practitioner to take control of a financially troubled company's affairs. By submitting this Standard Application Notice to Court, the company seeks to gain court approval to enter administration, which is aimed at protecting the interests of the company's creditors and stakeholders while exploring options for possible recovery or restructuring.
The template typically includes crucial details such as the name and address of the company, a summary of the company's financial position, the reasons for seeking administration, and the proposed administrator's information. It may also outline any potential adverse effects that could arise from delaying or denying the administration request, emphasizing the urgency of court intervention.
This legal document plays a vital role in initiating the company administration process within the confines of UK law. It ensures that all necessary information is provided to the court, helping to establish a transparent and fair process for all parties involved.
