All Templates
Provide collateral warranty
🏠 Collateral warranty
Environmental Consultant's Collateral Warranty (Funder, Buyer Or Tenant Friendly)
Environmental Consultant's Collateral Warranty (Funder, Buyer Or Tenant Friendly)
Publisher one
Genie AISource file
environmental_consultant's_collateral_warranty_(funder,_buyer_or_tenant_friendly)_template.docxJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Provide collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
The legal template of an "Environmental Consultant's Collateral Warranty (Funder, Buyer, or Tenant Friendly) under UK law" is designed to establish a contractual agreement between three parties: an environmental consultant, a funder (such as a bank or financial institution), and either a buyer or tenant.
In the context of environmental assessment and management, an environmental consultant is typically engaged to evaluate the potential environmental impact of a project, property, or development. Their role is to identify any existing or potential environmental issues, provide recommendations for mitigation measures, and ensure compliance with relevant environmental regulations and standards.
This template aims to create an additional layer of legal protection for the funder (e.g., providing funding for the project or property purchase/lease) or the buyer/tenant (acquiring/occupying the property), by securing a separate warranty directly from the environmental consultant.
The collateral warranty serves as a legal guarantee that the environmental consultant will perform their services with due diligence, in line with professional standards, and within the agreed scope of work. The warranty usually includes provisions holding the consultant liable for any errors, omissions, or negligence resulting in environmental harm or non-compliance with applicable laws and regulations.
The template is designed to be "funder, buyer, or tenant friendly," meaning that it is intended to protect the interests of these parties by clearly specifying their rights, remedies, and limitation periods in case of breach by the environmental consultant. It may also cover the cost of rectifying any environmental issues identified as a result of the consultant's failings, or compensation for any related losses incurred by the funder, buyer, or tenant.
Since this template is drafted under UK law, it would comply with the legal requirements and regulations governing environmental consultancy contracts within the United Kingdom. Legal professionals should review and adapt the template as needed to reflect the specific circumstances and requirements of the parties involved in order to safeguard their interests effectively and maintain compliance with applicable laws.
In the context of environmental assessment and management, an environmental consultant is typically engaged to evaluate the potential environmental impact of a project, property, or development. Their role is to identify any existing or potential environmental issues, provide recommendations for mitigation measures, and ensure compliance with relevant environmental regulations and standards.
This template aims to create an additional layer of legal protection for the funder (e.g., providing funding for the project or property purchase/lease) or the buyer/tenant (acquiring/occupying the property), by securing a separate warranty directly from the environmental consultant.
The collateral warranty serves as a legal guarantee that the environmental consultant will perform their services with due diligence, in line with professional standards, and within the agreed scope of work. The warranty usually includes provisions holding the consultant liable for any errors, omissions, or negligence resulting in environmental harm or non-compliance with applicable laws and regulations.
The template is designed to be "funder, buyer, or tenant friendly," meaning that it is intended to protect the interests of these parties by clearly specifying their rights, remedies, and limitation periods in case of breach by the environmental consultant. It may also cover the cost of rectifying any environmental issues identified as a result of the consultant's failings, or compensation for any related losses incurred by the funder, buyer, or tenant.
Since this template is drafted under UK law, it would comply with the legal requirements and regulations governing environmental consultancy contracts within the United Kingdom. Legal professionals should review and adapt the template as needed to reflect the specific circumstances and requirements of the parties involved in order to safeguard their interests effectively and maintain compliance with applicable laws.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Witness Statement Supporting Application Of Enforcement of Adjudication
This legal template is designed to assist individuals or businesses applying for the enforcement of an adjudication decision under UK law. An adjudication decision is a binding decision made by an adjudicator, typically appointed to resolve disputes related to construction projects or other contractual matters.
The template provides a structure for a witness statement, which is a written account of facts and evidence that a witness must provide to support the application for enforcement. This statement typically outlines the witness's knowledge, involvement, or observations related to the dispute and the adjudication process.
The purpose of this template is to ensure that the witness statement is organized, comprehensive, and aligned with the requirements set forth by UK law. It may include sections to summarize the witness's background, their relationship with the parties involved, detailed chronology of events leading to the dispute, and specific details about the adjudication procedure, including any relevant documents or correspondence.
By using this template, applicants can provide a well-structured witness statement that strengthens their case for the enforcement of the adjudication decision. It helps maintain consistency and clarity in the legal document, thereby increasing the chance of a successful outcome in the enforcement proceedings.
The template provides a structure for a witness statement, which is a written account of facts and evidence that a witness must provide to support the application for enforcement. This statement typically outlines the witness's knowledge, involvement, or observations related to the dispute and the adjudication process.
The purpose of this template is to ensure that the witness statement is organized, comprehensive, and aligned with the requirements set forth by UK law. It may include sections to summarize the witness's background, their relationship with the parties involved, detailed chronology of events leading to the dispute, and specific details about the adjudication procedure, including any relevant documents or correspondence.
By using this template, applicants can provide a well-structured witness statement that strengthens their case for the enforcement of the adjudication decision. It helps maintain consistency and clarity in the legal document, thereby increasing the chance of a successful outcome in the enforcement proceedings.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
1
DISCUSSIONS
2
Withholding Notice (Construction Contract)
The Withholding Notice (Construction Contract) legal template under UK law is a document used in the construction industry to provide formal notification of withholding payment to a contractor or subcontractor. This template is typically utilized when there are legitimate concerns or disputes regarding the quality of work, completion delays, breach of contract, or any other contractual issues that justify withholding payment.
The template outlines the relevant details such as project information, parties involved, and the specific reasons for withholding payment. It incorporates the necessary legal language and provisions required by UK law to ensure compliance and protection of both parties' rights. Additionally, it may include the amount being withheld, the date the notice is being issued, and any applicable deadlines for rectifying the mentioned issues.
By using this template, it allows the withholding party to communicate their concerns clearly and formally to the contractor, highlighting any breach or non-compliance that has occurred under the construction contract. This document serves as a vital tool in resolving disputes and initiating discussions for potential resolution prior to progressing to more formal legal actions or arbitration.
It is important to note that the Withholding Notice (Construction Contract) template under UK law should be reviewed by legal professionals who are specialized in construction law or litigation to ensure its suitability and compliance with the specific circumstances and jurisdiction.
The template outlines the relevant details such as project information, parties involved, and the specific reasons for withholding payment. It incorporates the necessary legal language and provisions required by UK law to ensure compliance and protection of both parties' rights. Additionally, it may include the amount being withheld, the date the notice is being issued, and any applicable deadlines for rectifying the mentioned issues.
By using this template, it allows the withholding party to communicate their concerns clearly and formally to the contractor, highlighting any breach or non-compliance that has occurred under the construction contract. This document serves as a vital tool in resolving disputes and initiating discussions for potential resolution prior to progressing to more formal legal actions or arbitration.
It is important to note that the Withholding Notice (Construction Contract) template under UK law should be reviewed by legal professionals who are specialized in construction law or litigation to ensure its suitability and compliance with the specific circumstances and jurisdiction.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
3
RATINGS
3
DISCUSSIONS
0
Witness Statement In Opposition To Summary Judgment Application
This legal template is a document that allows an individual, often referred to as the witness, to provide their statement and arguments opposing a summary judgment application under UK law. Summary judgment is a legal procedure used to promptly resolve a case by determining whether there is any genuine issue to be tried or if the opposing party has a valid defense or claim. In this template, the witness can outline their evidence, arguments, and any relevant facts that support their opposition to the summary judgment application. The template is tailored specifically for the legal system in the United Kingdom and aims to assist individuals in presenting a comprehensive and compelling case against the granting of summary judgment.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
0
DISCUSSIONS
2
