Contractor's Collateral Warranty (To Purchaser/Tenant)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Create collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
The template likely includes key provisions such as a clear definition of the parties involved, the scope of work or services provided by the contractor, and a detailed description of the specific obligations and warranties agreed upon. It may also outline procedures for dispute resolution, limitations of liability, insurance requirements, and any terms related to termination or transfer of the warranty.
The purpose of this collateral warranty is to extend additional protection and assurances to the purchaser or tenant, typically in circumstances where they might not have a direct contractual relationship with the contractor. This could occur when a third-party contractor is engaged by the main party involved in a construction or property development project, such as a developer or a landlord. By signing this warranty, the contractor acknowledges their legal obligations towards the purchaser or tenant and commits to meeting specific standards and providing a certain level of service.
It is important to note that this description provides a general understanding of what the legal template could entail, but the specifics and details of the document will depend on the content and requirements of the particular situation or project. Legal advice should always be sought to ensure the accuracy and applicability of any legal template.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Site Manager Contract
This Site Manager contract template is designed for a commercial site management organisation (or an individual site manager) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of site management and site-management-related services to be completed by the site manager on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the site management firm or individual site manager on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
Publisher
Genie AIJurisdiction
England and WalesStandard Application Notice to Court (Company Administration)
Company administration is a legal process that involves appointing an insolvency practitioner to take control of a financially troubled company's affairs. By submitting this Standard Application Notice to Court, the company seeks to gain court approval to enter administration, which is aimed at protecting the interests of the company's creditors and stakeholders while exploring options for possible recovery or restructuring.
The template typically includes crucial details such as the name and address of the company, a summary of the company's financial position, the reasons for seeking administration, and the proposed administrator's information. It may also outline any potential adverse effects that could arise from delaying or denying the administration request, emphasizing the urgency of court intervention.
This legal document plays a vital role in initiating the company administration process within the confines of UK law. It ensures that all necessary information is provided to the court, helping to establish a transparent and fair process for all parties involved.
