All Templates
Provide collateral warranty
🏠 Collateral warranty
Contractor's Collateral Warranty (Pro-Purchaser)
Contractor's Collateral Warranty (Pro-Purchaser)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Provide collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
A Contractor's Collateral Warranty (Pro-Purchaser) is a legal template document designed to outline the additional assurances and guarantees provided by a contractor to a purchaser of a construction project in the United Kingdom (UK). This warranty serves as an agreement between the contractor and the purchaser, offering added protection to the purchaser beyond the primary contract between the contractor and the project owner.
The template typically covers various aspects, including the contractor's obligations, liability, and warranty provisions specifically tailored in favor of the purchaser. It aims to supplement the existing contractual relationship by providing direct recourse and a higher level of legal security for the purchaser.
Within the context of a construction project, a collateral warranty can offer numerous benefits to a purchaser. It might stipulate that the contractor will rectify defects, address issues not covered in the main contract, or extend the period of liability. This agreement can also guarantee that the contractor will provide important documentation, instruction manuals, and warranties for any equipment or systems installed.
The template generally incorporates legal provisions aligned with UK law to ensure its validity and enforceability in local jurisdictions. It can be customized to suit the specific needs of the project and the purchaser, considering factors such as project scope, duration, complexity, and associated risks.
Using a pro-purchaser approach, this collateral warranty template seeks to safeguard the purchaser's rights by granting them direct access to the contractor's guarantees. This document is valuable in providing the purchaser with additional legal protections and assurances, thereby minimizing potential risks, improving confidence, and facilitating smoother project delivery in the construction industry in the UK.
The template typically covers various aspects, including the contractor's obligations, liability, and warranty provisions specifically tailored in favor of the purchaser. It aims to supplement the existing contractual relationship by providing direct recourse and a higher level of legal security for the purchaser.
Within the context of a construction project, a collateral warranty can offer numerous benefits to a purchaser. It might stipulate that the contractor will rectify defects, address issues not covered in the main contract, or extend the period of liability. This agreement can also guarantee that the contractor will provide important documentation, instruction manuals, and warranties for any equipment or systems installed.
The template generally incorporates legal provisions aligned with UK law to ensure its validity and enforceability in local jurisdictions. It can be customized to suit the specific needs of the project and the purchaser, considering factors such as project scope, duration, complexity, and associated risks.
Using a pro-purchaser approach, this collateral warranty template seeks to safeguard the purchaser's rights by granting them direct access to the contractor's guarantees. This document is valuable in providing the purchaser with additional legal protections and assurances, thereby minimizing potential risks, improving confidence, and facilitating smoother project delivery in the construction industry in the UK.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Witness Statement Supporting Application Of Enforcement of Adjudication
This legal template is designed to assist individuals or businesses applying for the enforcement of an adjudication decision under UK law. An adjudication decision is a binding decision made by an adjudicator, typically appointed to resolve disputes related to construction projects or other contractual matters.
The template provides a structure for a witness statement, which is a written account of facts and evidence that a witness must provide to support the application for enforcement. This statement typically outlines the witness's knowledge, involvement, or observations related to the dispute and the adjudication process.
The purpose of this template is to ensure that the witness statement is organized, comprehensive, and aligned with the requirements set forth by UK law. It may include sections to summarize the witness's background, their relationship with the parties involved, detailed chronology of events leading to the dispute, and specific details about the adjudication procedure, including any relevant documents or correspondence.
By using this template, applicants can provide a well-structured witness statement that strengthens their case for the enforcement of the adjudication decision. It helps maintain consistency and clarity in the legal document, thereby increasing the chance of a successful outcome in the enforcement proceedings.
The template provides a structure for a witness statement, which is a written account of facts and evidence that a witness must provide to support the application for enforcement. This statement typically outlines the witness's knowledge, involvement, or observations related to the dispute and the adjudication process.
The purpose of this template is to ensure that the witness statement is organized, comprehensive, and aligned with the requirements set forth by UK law. It may include sections to summarize the witness's background, their relationship with the parties involved, detailed chronology of events leading to the dispute, and specific details about the adjudication procedure, including any relevant documents or correspondence.
By using this template, applicants can provide a well-structured witness statement that strengthens their case for the enforcement of the adjudication decision. It helps maintain consistency and clarity in the legal document, thereby increasing the chance of a successful outcome in the enforcement proceedings.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
1
DISCUSSIONS
2
Withholding Notice (Construction Contract)
The Withholding Notice (Construction Contract) legal template under UK law is a document used in the construction industry to provide formal notification of withholding payment to a contractor or subcontractor. This template is typically utilized when there are legitimate concerns or disputes regarding the quality of work, completion delays, breach of contract, or any other contractual issues that justify withholding payment.
The template outlines the relevant details such as project information, parties involved, and the specific reasons for withholding payment. It incorporates the necessary legal language and provisions required by UK law to ensure compliance and protection of both parties' rights. Additionally, it may include the amount being withheld, the date the notice is being issued, and any applicable deadlines for rectifying the mentioned issues.
By using this template, it allows the withholding party to communicate their concerns clearly and formally to the contractor, highlighting any breach or non-compliance that has occurred under the construction contract. This document serves as a vital tool in resolving disputes and initiating discussions for potential resolution prior to progressing to more formal legal actions or arbitration.
It is important to note that the Withholding Notice (Construction Contract) template under UK law should be reviewed by legal professionals who are specialized in construction law or litigation to ensure its suitability and compliance with the specific circumstances and jurisdiction.
The template outlines the relevant details such as project information, parties involved, and the specific reasons for withholding payment. It incorporates the necessary legal language and provisions required by UK law to ensure compliance and protection of both parties' rights. Additionally, it may include the amount being withheld, the date the notice is being issued, and any applicable deadlines for rectifying the mentioned issues.
By using this template, it allows the withholding party to communicate their concerns clearly and formally to the contractor, highlighting any breach or non-compliance that has occurred under the construction contract. This document serves as a vital tool in resolving disputes and initiating discussions for potential resolution prior to progressing to more formal legal actions or arbitration.
It is important to note that the Withholding Notice (Construction Contract) template under UK law should be reviewed by legal professionals who are specialized in construction law or litigation to ensure its suitability and compliance with the specific circumstances and jurisdiction.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
3
RATINGS
3
DISCUSSIONS
0
Witness Statement In Opposition To Summary Judgment Application
This legal template is a document that allows an individual, often referred to as the witness, to provide their statement and arguments opposing a summary judgment application under UK law. Summary judgment is a legal procedure used to promptly resolve a case by determining whether there is any genuine issue to be tried or if the opposing party has a valid defense or claim. In this template, the witness can outline their evidence, arguments, and any relevant facts that support their opposition to the summary judgment application. The template is tailored specifically for the legal system in the United Kingdom and aims to assist individuals in presenting a comprehensive and compelling case against the granting of summary judgment.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
0
DISCUSSIONS
2
