Contractor Agreement For House (Construction) Template for Switzerland

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Contractor Agreement For House (Construction)

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Contractor Agreement For House (Construction)

"I need a Contractor Agreement For House (Construction) for building a new eco-friendly residential property in Zurich, incorporating solar panel installation and sustainable materials, with construction planned to start in March 2025."

Document background

The Contractor Agreement For House (Construction) is a vital legal document used in Switzerland when engaging a contractor for residential construction projects. It serves as the primary contract between property owners and construction contractors, establishing their rights, obligations, and responsibilities under Swiss law. The agreement must comply with the Swiss Code of Obligations, cantonal building regulations, and widely-recognized SIA norms, particularly SIA 118. This document is essential for projects ranging from new home construction to major residential renovations, providing detailed specifications for construction work, payment terms, quality standards, and dispute resolution mechanisms. It includes provisions for insurance requirements, warranty periods, and environmental compliance specific to Swiss construction standards. The agreement's structure reflects Swiss legal requirements while incorporating practical considerations for effective project execution and risk management.

Suggested Sections

1. Parties: Identification and details of the property owner (client) and the contractor, including full legal names, addresses, and registration details if applicable

2. Background: Context of the agreement, including brief description of the construction project and property details

3. Definitions: Definitions of key terms used throughout the agreement, including technical construction terms

4. Scope of Work: Detailed description of the construction work to be performed, including specific deliverables and exclusions

5. Contract Price and Payment Terms: Total contract value, payment schedule, payment methods, and conditions for payment

6. Timeline and Completion: Project schedule, completion date, milestones, and provisions for extensions of time

7. Contractor's Obligations: Key responsibilities including quality standards, compliance with regulations, workforce management, and site safety

8. Client's Obligations: Client's responsibilities including site access, permits, approvals, and timely decision-making

9. Materials and Equipment: Specifications for materials, procurement responsibilities, and quality requirements

10. Variations and Changes: Process for handling changes to scope, pricing, or timeline

11. Quality and Inspection: Quality standards, inspection procedures, and acceptance criteria

12. Warranties and Defects: Warranty periods, defect resolution process, and liability provisions as per Swiss law

13. Insurance and Liability: Required insurance coverage and allocation of risks between parties

14. Termination: Grounds and procedures for contract termination by either party

15. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures

16. General Provisions: Standard legal provisions including notices, governing law, and entire agreement clause

Optional Sections

1. Environmental Protection Measures: Specific environmental requirements and compliance measures, used when project has significant environmental impact

2. Subcontractors: Terms governing the use and management of subcontractors, included when subcontracting is permitted

3. Intellectual Property: Protection of designs, plans, and other IP, included when custom designs or innovative solutions are involved

4. Force Majeure: Provisions for unforeseen circumstances, particularly relevant for longer projects

5. Site Security: Special security requirements, included for sensitive locations or high-value projects

6. Temporary Works: Provisions for temporary structures and facilities, needed for complex construction projects

7. Hazardous Materials: Special provisions for handling hazardous materials, included when relevant to the project

8. Liquidated Damages: Pre-agreed compensation for specific breaches, included when parties want certainty on damages

Suggested Schedules

1. Schedule 1: Technical Specifications: Detailed technical requirements, construction methods, and quality standards

2. Schedule 2: Plans and Drawings: Architectural plans, engineering drawings, and design details

3. Schedule 3: Bill of Quantities: Itemized list of materials, quantities, and unit prices

4. Schedule 4: Project Timeline: Detailed project schedule with milestones and critical path

5. Schedule 5: Payment Schedule: Detailed breakdown of payment installments and conditions

6. Schedule 6: Site Information: Site surveys, geological reports, and existing condition documentation

7. Schedule 7: Insurance Requirements: Detailed insurance specifications and coverage requirements

8. Schedule 8: Key Personnel: List of key project personnel and their responsibilities

9. Appendix A: Building Permits: Copies of relevant permits and authorizations

10. Appendix B: Safety Procedures: Detailed safety protocols and emergency procedures

11. Appendix C: Quality Control Plan: Specific quality control measures and testing requirements

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Construction

Real Estate

Property Development

Architecture

Engineering

Building Materials

Construction Equipment

Property Management

Infrastructure Development

Home Building

Relevant Teams

Legal

Construction

Project Management

Property Development

Procurement

Risk and Compliance

Real Estate

Contract Administration

Quality Assurance

Operations

Relevant Roles

Construction Project Manager

Property Developer

Real Estate Manager

Construction Site Supervisor

Contract Administrator

Legal Counsel

Architect

Structural Engineer

Quantity Surveyor

Building Inspector

Construction Manager

Compliance Officer

Risk Manager

Procurement Manager

Property Owner

General Contractor

Find the exact document you need

Construction Agreement Between Builder And Owner

Swiss law-governed agreement between a property owner and builder setting out terms for construction works, incorporating federal and cantonal requirements.

How Genie AI reduced drafting time by 75% for a legal firm

Let's create your Contractor Agreement For House (Construction)

Authors

Alex Denne

Find the exact document you need

Construction Agreement Between Builder And Owner

Labor Contract For (Construction)

Contractor Agreement For House (Construction)

Standard Independent Contractor Contract

Construction Contract

Contractor Contract Agreement

Contract For Project Management Services

Non Compete Agreement For Contractors

General Contractor Terms And Conditions With Proposal

Freelance Contractor Agreement

Sole Trader Contract

Simple Subcontractor Agreement

Contractor Service Agreement

Percentage Agreement Contract

Framework Agreement Contract

Contract For Cleaning Services Agreement

Binding Agreement Contract

Agreement For Construction Of House

Agreement Between Contractor And Client

Simple Service Agreement Contract

Temporary Contractor Agreement

Salon Independent Contractor Agreement

General Employment Contract

Agreement Contract Between Employer And Employees

Electrical Service Contract

Real Estate Agent Agreement Contract

Work Order Contract Agreement

Real Estate Independent Contractor Agreement

Legal Agreement Contract

Labor Agreement Contract

House Painting Contract

Model Agreement Contract

Staffing Agreement Contract

Property Agreement Contract

Fabrication Contract Agreement

Home Improvement Contract Agreement

Real Estate Agreement Contract

General Service Contract

Liability Agreement Contract

Electrical Contractor Contract

Work Order Contract

Work Agreement Contract

Product Agreement Contract

Outsourcing Contract Agreement

Cost Plus Contractor Agreement

Software Contractor Agreement

Settlement Agreement Contract

Joint Venture Construction Agreement

Contractor Employment Agreement

Payment Plan Agreement Contract

Self Employment Agreement

Partner Agreement Contract

Home Renovation Contract

House Agreement Contract

Standard Independent Contractor Agreement

Simple Independent Contractor Agreement

Business Agreement Contract

Download our whitepaper on the future of AI in Legal

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security

Innovation in privacy:

Want to know more?

Commercial

Employment

IP

Administration

Finance

R&D

Use Cases