Pay Less Notice (Construction Contract)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Pay less noticeBusiness activity
Pay less noticeA pay less notice is a notice served by a contractor to a sub-contractor that sets out the sum the contractor considers to be due under the sub-contract. The notice must be served before the final date for payment stated in the sub-contract. If the sub-contractor does not agree with the sum stated in the pay less notice, they can serve a notice of intention to withhold payment.
The Pay Less Notice (Construction Contract) is a legal template commonly used in the United Kingdom within the construction industry. This document serves as a formal notice to the contractor from the employer, highlighting the intention to pay an amount less than the sum usually invoiced for the completed work or ongoing project.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Rule 30 Standard Letter To Notify Opposition In Employment Tribunal Of Application For An Order
The legal template titled "Rule 30 Standard Letter To Notify Opposition In Employment Tribunal Of Application For An Order" is specifically designed to assist individuals or legal professionals in the UK who are seeking to inform the opposing party about their application for an order in an employment tribunal.
Under UK law, Rule 30 establishes the guidelines for communicating and notifying the opposing party about various applications made in an employment tribunal. This template serves as a standard letter format, ensuring compliance with the rules while providing a formal means of communication.
The template may include sections covering essential details such as the parties involved, the case reference number, and the specific order being sought. It will outline the reasons behind the application and may provide supporting evidence or legal arguments. It is crucial for the letter to be concise, precise, and adhere strictly to the requirements outlined in Rule 30 to ensure its validity and effectiveness in the tribunal proceedings.
Overall, this legal template serves as a valuable tool for those navigating the UK employment tribunal system and seeking to notify their opposition professionally and in accordance with the relevant legal framework.
Under UK law, Rule 30 establishes the guidelines for communicating and notifying the opposing party about various applications made in an employment tribunal. This template serves as a standard letter format, ensuring compliance with the rules while providing a formal means of communication.
The template may include sections covering essential details such as the parties involved, the case reference number, and the specific order being sought. It will outline the reasons behind the application and may provide supporting evidence or legal arguments. It is crucial for the letter to be concise, precise, and adhere strictly to the requirements outlined in Rule 30 to ensure its validity and effectiveness in the tribunal proceedings.
Overall, this legal template serves as a valuable tool for those navigating the UK employment tribunal system and seeking to notify their opposition professionally and in accordance with the relevant legal framework.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
3
DISCUSSIONS
1
Simple Social Media Policy For Employees (UK)
This legal template, titled "Simple Social Media Policy For Employees (UK) under UK law," provides guidelines and regulations for employees regarding their social media usage in compliance with UK laws.
This document aims to establish clear rules and expectations for employees when utilizing social media platforms, both personally and professionally. It primarily emphasizes the importance of maintaining a positive online reputation and protecting the confidentiality and integrity of the organization.
The template covers various aspects including, but not limited to:
1. Scope: Defining the policy's applicability to all employees and platforms, including personal social media accounts that may impact the employer or work environment.
2. Social Media Usage Guidelines: Outlining acceptable and unacceptable behavior, emphasizing the importance of responsible usage, respectful communication, and adhering to intellectual property rights and legal obligations.
3. Confidentiality and Privacy: Addressing the need to safeguard confidential company information and respecting the privacy rights of the organization, its employees, clients, and partners.
4. Endorsements and Disclaimers: Providing guidelines for employees when endorsing products, services, or the company itself, and requiring the inclusion of appropriate disclaimers to avoid potential legal or ethical issues.
5. Protection against Harassment and Discrimination: Highlighting the prohibition of any discriminatory, offensive, or derogatory content that can harm individuals or damage the organization's reputation, in accordance with UK equality laws.
6. Monitoring and Enforcement: Clarifying the organization's right to monitor and investigate employee social media activities, and explaining the potential consequences for violating the policy, which may include disciplinary action, up to and including termination.
7. Training and Awareness: Encouraging employees to stay up-to-date on social media best practices and organizing periodic training sessions to minimize legal risks and enhance their understanding of the policy.
This template is intended to serve as a starting point, allowing organizations in the UK to create their own tailored social media policy aligned with UK laws. It provides employers with a legally sound framework to promote responsible social media usage while protecting the organization's interests and maintaining a positive online presence.
This document aims to establish clear rules and expectations for employees when utilizing social media platforms, both personally and professionally. It primarily emphasizes the importance of maintaining a positive online reputation and protecting the confidentiality and integrity of the organization.
The template covers various aspects including, but not limited to:
1. Scope: Defining the policy's applicability to all employees and platforms, including personal social media accounts that may impact the employer or work environment.
2. Social Media Usage Guidelines: Outlining acceptable and unacceptable behavior, emphasizing the importance of responsible usage, respectful communication, and adhering to intellectual property rights and legal obligations.
3. Confidentiality and Privacy: Addressing the need to safeguard confidential company information and respecting the privacy rights of the organization, its employees, clients, and partners.
4. Endorsements and Disclaimers: Providing guidelines for employees when endorsing products, services, or the company itself, and requiring the inclusion of appropriate disclaimers to avoid potential legal or ethical issues.
5. Protection against Harassment and Discrimination: Highlighting the prohibition of any discriminatory, offensive, or derogatory content that can harm individuals or damage the organization's reputation, in accordance with UK equality laws.
6. Monitoring and Enforcement: Clarifying the organization's right to monitor and investigate employee social media activities, and explaining the potential consequences for violating the policy, which may include disciplinary action, up to and including termination.
7. Training and Awareness: Encouraging employees to stay up-to-date on social media best practices and organizing periodic training sessions to minimize legal risks and enhance their understanding of the policy.
This template is intended to serve as a starting point, allowing organizations in the UK to create their own tailored social media policy aligned with UK laws. It provides employers with a legally sound framework to promote responsible social media usage while protecting the organization's interests and maintaining a positive online presence.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
12
RATINGS
5
DISCUSSIONS
1
Article 15 Letter Of Request For Data Subject Access
The legal template titled "Article 15 Letter of Request for Data Subject Access under UK law" is a formal document used by individuals or organizations in the United Kingdom to exercise their right to access personal data held by data controllers or processors.
Under the General Data Protection Regulation (GDPR), individuals have the right to request access to their personal information held by an organization. Article 15 of the GDPR specifically outlines these rights, stating that data subjects have the right to obtain confirmation about the existence and processing of their personal data.
This template provides a structured format for the letter of request, ensuring that all necessary information is included. It may include details such as the data subject's name, contact information, and any relevant identification or reference numbers. Additionally, the template may outline the specific data requests, including the purpose for the request and the desired format of the received information.
By utilizing this template, data subjects can assert their right to access and review personal data in the possession of the data controller or processor. This document serves as a formal request, enabling individuals to obtain clarity on the data being processed and confirm its accuracy, lawfulness, and transparency.
Under the General Data Protection Regulation (GDPR), individuals have the right to request access to their personal information held by an organization. Article 15 of the GDPR specifically outlines these rights, stating that data subjects have the right to obtain confirmation about the existence and processing of their personal data.
This template provides a structured format for the letter of request, ensuring that all necessary information is included. It may include details such as the data subject's name, contact information, and any relevant identification or reference numbers. Additionally, the template may outline the specific data requests, including the purpose for the request and the desired format of the received information.
By utilizing this template, data subjects can assert their right to access and review personal data in the possession of the data controller or processor. This document serves as a formal request, enabling individuals to obtain clarity on the data being processed and confirm its accuracy, lawfulness, and transparency.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
7
RATINGS
4
DISCUSSIONS
1
