Pay Less Notice (Construction Contract)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Pay less noticeBusiness activity
Pay less noticeA pay less notice is a notice served by a contractor to a sub-contractor that sets out the sum the contractor considers to be due under the sub-contract. The notice must be served before the final date for payment stated in the sub-contract. If the sub-contractor does not agree with the sum stated in the pay less notice, they can serve a notice of intention to withhold payment.
The Pay Less Notice (Construction Contract) is a legal template commonly used in the United Kingdom within the construction industry. This document serves as a formal notice to the contractor from the employer, highlighting the intention to pay an amount less than the sum usually invoiced for the completed work or ongoing project.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Standard Extra Employment Contract Clauses
This legal template provides a comprehensive set of Standard Extra Employment Contract Clauses under UK law, aimed at addressing specific terms and conditions that can be incorporated into an employment contract. These additional clauses go beyond the basic employment agreement to cover a wide range of aspects related to the employer-employee relationship.
The template focuses on UK law, ensuring compliance with relevant legislation and providing clarity for both parties involved. It includes information on essential topics such as working hours, holiday entitlement, sick leave, and notice periods. In addition, the clauses cover provisions for confidentiality, intellectual property rights, and post-employment restrictions.
Furthermore, the template outlines guidelines for performance reviews, training and development, and grievance procedures to facilitate effective communication and dispute resolution. It also addresses matters related to compensation, bonuses, and benefits, including potential incentives or bonus schemes that the employer may offer.
Importantly, the Standard Extra Employment Contract Clauses template provides a framework for fair and equitable treatment, emphasizing anti-discrimination policies, health and safety regulations, and accommodation for reasonable adjustments. It ensures that both parties are protected in terms of their rights and responsibilities throughout the employment relationship.
Employers can customize and incorporate these clauses into their employment contracts, tailoring them to meet their specific business requirements while adhering to UK employment laws and regulations. Similarly, employees can familiarize themselves with the clauses to better understand their rights and obligations within the employment context.
By utilizing this template, employers and employees can establish a solid foundation for their working relationship, enhancing clarity, transparency, and legal compliance.
The template focuses on UK law, ensuring compliance with relevant legislation and providing clarity for both parties involved. It includes information on essential topics such as working hours, holiday entitlement, sick leave, and notice periods. In addition, the clauses cover provisions for confidentiality, intellectual property rights, and post-employment restrictions.
Furthermore, the template outlines guidelines for performance reviews, training and development, and grievance procedures to facilitate effective communication and dispute resolution. It also addresses matters related to compensation, bonuses, and benefits, including potential incentives or bonus schemes that the employer may offer.
Importantly, the Standard Extra Employment Contract Clauses template provides a framework for fair and equitable treatment, emphasizing anti-discrimination policies, health and safety regulations, and accommodation for reasonable adjustments. It ensures that both parties are protected in terms of their rights and responsibilities throughout the employment relationship.
Employers can customize and incorporate these clauses into their employment contracts, tailoring them to meet their specific business requirements while adhering to UK employment laws and regulations. Similarly, employees can familiarize themselves with the clauses to better understand their rights and obligations within the employment context.
By utilizing this template, employers and employees can establish a solid foundation for their working relationship, enhancing clarity, transparency, and legal compliance.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
11
RATINGS
3
DISCUSSIONS
1
Employer's Holding Response Letter To Data Request (Data Subject Rights Under GDPR)
The legal template "Employer's Holding Response Letter to Data Request (Data Subject Rights Under GDPR) under UK law" is a document created to address the obligations of employers in the United Kingdom (UK) regarding data subject rights outlined in the General Data Protection Regulation (GDPR). The GDPR is a comprehensive set of data protection laws that regulates the processing and handling of personal data within the European Union (EU), including the UK.
This template provides employers with a pre-drafted letter to respond to data subject requests made by individuals whose personal data the employer processes. It is applicable to situations where an employer receives a request from an employee or former employee, job applicant, or any other individual who holds the status of a data subject under the GDPR.
The letter acts as an initial response to acknowledge the receipt of the data subject's request. It informs the data subject that their request has been received, understood, and will be processed as per the GDPR guidelines. The template might include specific sections explaining the purpose of the data subject's request, outlining the timeframe within which the employer will respond, and acknowledging the data subject's rights related to their personal data (e.g., access, rectification, erasure, restriction, objection, data portability).
Additionally, the template may provide instructions to the data subject on how they can further exercise their rights or provide any necessary supporting documents to validate their request. It might also include a disclaimer, stating any limitations or exceptions to the data subject's rights as prescribed by the GDPR or other applicable legislation.
Employers can tailor this template to their specific circumstances, ensuring compliance with UK data protection laws and GDPR requirements.
This template provides employers with a pre-drafted letter to respond to data subject requests made by individuals whose personal data the employer processes. It is applicable to situations where an employer receives a request from an employee or former employee, job applicant, or any other individual who holds the status of a data subject under the GDPR.
The letter acts as an initial response to acknowledge the receipt of the data subject's request. It informs the data subject that their request has been received, understood, and will be processed as per the GDPR guidelines. The template might include specific sections explaining the purpose of the data subject's request, outlining the timeframe within which the employer will respond, and acknowledging the data subject's rights related to their personal data (e.g., access, rectification, erasure, restriction, objection, data portability).
Additionally, the template may provide instructions to the data subject on how they can further exercise their rights or provide any necessary supporting documents to validate their request. It might also include a disclaimer, stating any limitations or exceptions to the data subject's rights as prescribed by the GDPR or other applicable legislation.
Employers can tailor this template to their specific circumstances, ensuring compliance with UK data protection laws and GDPR requirements.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
11
RATINGS
4
DISCUSSIONS
2
Application To The Employment Tribunal To Withdraw Claim (All or Part)
The legal template titled "Application To The Employment Tribunal To Withdraw Claim (All or Part)" under UK law provides a formal document for individuals involved in an ongoing employment tribunal case who wish to withdraw their claim partially or in its entirety. This template helps individuals navigate the legal process by providing a clear structure and guidelines to follow when withdrawing their claim before the Employment Tribunal.
Typically, an individual may choose to withdraw their claim due to various reasons, such as reaching a settlement agreement with the opposing party, obtaining new evidence that weakens their case, or simply deciding not to pursue the legal action any further. By submitting this application to the Employment Tribunal, the individual expresses their intention to withdraw part or all of their claim and formally requests the tribunal's permission to do so.
The template will include sections for the claimant's personal information, details of the ongoing case, and the specific parts of the claim they wish to withdraw. Additionally, it may require the individual to provide a thorough explanation for the withdrawal, supporting documents if applicable, and any other relevant information deemed necessary by the tribunal.
Using this legal template can help ensure that the proper legal procedure is followed in withdrawing a claim, protecting the rights and interests of all parties involved while maintaining transparency in the judicial process.
Typically, an individual may choose to withdraw their claim due to various reasons, such as reaching a settlement agreement with the opposing party, obtaining new evidence that weakens their case, or simply deciding not to pursue the legal action any further. By submitting this application to the Employment Tribunal, the individual expresses their intention to withdraw part or all of their claim and formally requests the tribunal's permission to do so.
The template will include sections for the claimant's personal information, details of the ongoing case, and the specific parts of the claim they wish to withdraw. Additionally, it may require the individual to provide a thorough explanation for the withdrawal, supporting documents if applicable, and any other relevant information deemed necessary by the tribunal.
Using this legal template can help ensure that the proper legal procedure is followed in withdrawing a claim, protecting the rights and interests of all parties involved while maintaining transparency in the judicial process.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
9
RATINGS
2
DISCUSSIONS
2
