Sub-Contractor Collateral Warranty (Pro-Employer)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Provide collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
The document covers various aspects related to the sub-contractor's responsibilities, performance expectations, and potential liabilities in relation to the employer and any third parties directly affected by the construction project. It outlines the scope of work for the sub-contractor, specifying the tasks, timelines, quality standards, and any applicable regulations or industry standards that must be adhered to.
Additionally, the template ensures that the sub-contractor provides the necessary warranties, guarantees, and indemnities to the employer. These provisions serve to safeguard the employer against any financial losses, damages, or delays caused by the sub-contractor's actions or omissions. The template may also include details about insurance requirements, in order to ensure that both parties are adequately covered throughout the duration of the project.
Furthermore, this template may address dispute resolution mechanisms, such as arbitration or mediation, to resolve any conflicts that may arise between the sub-contractor and the employer. It may also specify the governing law and jurisdiction under which any legal disputes will be resolved, which in this case is UK law.
Overall, the Sub-Contractor Collateral Warranty (Pro-Employer) template emphasizes the employer's interests by establishing a clear framework of obligations and liabilities for the sub-contractor. By utilizing this legal document, both parties can have a comprehensive understanding of their respective roles and responsibilities, providing a foundation for a smoother and more transparent working relationship.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Service Occupancy Agreement For Employee
The template covers various aspects such as the duration of the occupancy, the rental terms, the obligations of both the employer and employee, and the rights and responsibilities of each party. It includes provisions related to maintenance and repair responsibilities, payment of utility bills, access to the property, termination of the agreement, and potentially, the provisions for eviction.
This agreement template adheres to UK law and takes into consideration the specific regulations and requirements applicable to service occupancies. It ensures that both the employer and employee have a clear understanding of their rights and obligations, thereby preventing any potential disputes or misunderstandings regarding the use and occupation of the provided accommodation.
Publisher
Genie AIJurisdiction
England and WalesShift Manager Contract
This Shift Manager contract template is designed for a commercial shift management organisation (or an individual shift manager) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of shift management and shift-management-related services to be completed by the shift manager on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the shift management firm or individual shift manager on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
