All Templates
Provide collateral warranty
🏠 Collateral warranty
Sub-Contractor Collateral Warranty (Pro-Employer)
Sub-Contractor Collateral Warranty (Pro-Employer)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Provide collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
The legal template of the Sub-Contractor Collateral Warranty (Pro-Employer) under UK law is a comprehensive and standardized document that sets out the rights and obligations of a sub-contractor towards a third party employer in a construction project. This particular template is designed to heavily favor the employer's interests and offers additional protection to the employer in case of breach or negligence by the sub-contractor.
The document covers various aspects related to the sub-contractor's responsibilities, performance expectations, and potential liabilities in relation to the employer and any third parties directly affected by the construction project. It outlines the scope of work for the sub-contractor, specifying the tasks, timelines, quality standards, and any applicable regulations or industry standards that must be adhered to.
Additionally, the template ensures that the sub-contractor provides the necessary warranties, guarantees, and indemnities to the employer. These provisions serve to safeguard the employer against any financial losses, damages, or delays caused by the sub-contractor's actions or omissions. The template may also include details about insurance requirements, in order to ensure that both parties are adequately covered throughout the duration of the project.
Furthermore, this template may address dispute resolution mechanisms, such as arbitration or mediation, to resolve any conflicts that may arise between the sub-contractor and the employer. It may also specify the governing law and jurisdiction under which any legal disputes will be resolved, which in this case is UK law.
Overall, the Sub-Contractor Collateral Warranty (Pro-Employer) template emphasizes the employer's interests by establishing a clear framework of obligations and liabilities for the sub-contractor. By utilizing this legal document, both parties can have a comprehensive understanding of their respective roles and responsibilities, providing a foundation for a smoother and more transparent working relationship.
The document covers various aspects related to the sub-contractor's responsibilities, performance expectations, and potential liabilities in relation to the employer and any third parties directly affected by the construction project. It outlines the scope of work for the sub-contractor, specifying the tasks, timelines, quality standards, and any applicable regulations or industry standards that must be adhered to.
Additionally, the template ensures that the sub-contractor provides the necessary warranties, guarantees, and indemnities to the employer. These provisions serve to safeguard the employer against any financial losses, damages, or delays caused by the sub-contractor's actions or omissions. The template may also include details about insurance requirements, in order to ensure that both parties are adequately covered throughout the duration of the project.
Furthermore, this template may address dispute resolution mechanisms, such as arbitration or mediation, to resolve any conflicts that may arise between the sub-contractor and the employer. It may also specify the governing law and jurisdiction under which any legal disputes will be resolved, which in this case is UK law.
Overall, the Sub-Contractor Collateral Warranty (Pro-Employer) template emphasizes the employer's interests by establishing a clear framework of obligations and liabilities for the sub-contractor. By utilizing this legal document, both parties can have a comprehensive understanding of their respective roles and responsibilities, providing a foundation for a smoother and more transparent working relationship.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Voluntary Statement On Supply Chain Due Diligence For Companies Not Covered By Section 54 Of The MSA 2015
This legal template is designed to aid companies operating in the United Kingdom that are not subject to Section 54 of the Modern Slavery Act 2015 (MSA 2015), which relates to supply chain due diligence and transparency. The template provides a voluntary statement for such companies, outlining their commitment to carrying out supply chain due diligence to identify and prevent modern slavery practices within their operations. This statement serves to demonstrate the company's dedication to ethical practices and align with international standards, even though they are not legally obligated to do so under Section 54 of the MSA 2015. By adopting this template, companies can convey their proactive approach towards combatting modern slavery and promote transparency within their supply chains.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
1
RATINGS
3
DISCUSSIONS
2
Warehouse Part-Lease On Estate (Industrial Unit)
This legal template pertains to a Warehouse Part-Lease on Estate (Industrial Unit) under UK law. It is a comprehensive document that outlines the terms and conditions agreed upon between the landlord and tenant regarding the leasing of a portion of a warehouse or industrial unit situated on an estate. The template covers various important elements such as the duration of the lease, the rental amount, payment schedule, maintenance and repair responsibilities, access rights, use restrictions, and any additional provisions specific to UK law and regulations. It aims to provide a clear and legally binding agreement that protects the rights and obligations of both parties involved in the warehouse part-lease arrangement.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
0
DISCUSSIONS
2
Written Resolution Of Members To Approve A Guarantee (Private Company)
This legal template is used in the context of a private company located in the United Kingdom to document a written resolution of its members. The resolution pertains to the approval of a guarantee made by the company.
A guarantee, in legal terms, refers to a legally binding promise made by one party (the guarantor) to assume responsibility for the obligations or debts of another party (the debtor), in case the debtor fails to fulfill their obligations. By passing a written resolution, the members of the company collectively agree to accept the responsibilities and potential liabilities associated with providing such a guarantee.
The purpose of this template is to provide a standardized framework for recording the approval process, ensuring compliance with UK company laws and regulations. It includes essential information such as the company's details, the details of the guarantee being approved, and the agreement of the members to support and accept the associated risks.
By employing this template, the company ensures that the resolution to approve a guarantee is validly and transparently documented, protecting both the company's interests and the rights of its members. The template may serve as a vital legal record that can be referred to in the future if disputes or legal issues arise concerning the guarantee.
A guarantee, in legal terms, refers to a legally binding promise made by one party (the guarantor) to assume responsibility for the obligations or debts of another party (the debtor), in case the debtor fails to fulfill their obligations. By passing a written resolution, the members of the company collectively agree to accept the responsibilities and potential liabilities associated with providing such a guarantee.
The purpose of this template is to provide a standardized framework for recording the approval process, ensuring compliance with UK company laws and regulations. It includes essential information such as the company's details, the details of the guarantee being approved, and the agreement of the members to support and accept the associated risks.
By employing this template, the company ensures that the resolution to approve a guarantee is validly and transparently documented, protecting both the company's interests and the rights of its members. The template may serve as a vital legal record that can be referred to in the future if disputes or legal issues arise concerning the guarantee.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
8
RATINGS
5
DISCUSSIONS
3
