All Templates
Carry out property alteration
🛡️ Property maintenance / alteration licence
Standard License For Alterations
Standard License For Alterations
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useContract party
Relevant sectors
Type of legal document
🛡️ Property maintenance / alteration licenceBusiness activity
Carry out property alterationA property maintenance / alteration licence allows the holder to undertake specific work on a property, such as painting, minor renovations or repairs. The work must be carried out in accordance with the Building Code of Australia and other relevant laws.
The "Standard License For Alterations under UK Law" legal template is a document that outlines the terms and conditions for obtaining a license to make alterations or modifications to certain types of properties in the United Kingdom. This template is specifically tailored to comply with the legal requirements and regulations governing property alterations in the UK.
The template serves as a contractual framework between the property owner, referred to as the licensor, and the individual or entity seeking permission to carry out alterations, referred to as the licensee. It sets out the general terms under which the licensee can proceed with the proposed alterations, ensuring the licensor's interests are protected and the alterations comply with relevant legal and regulatory standards.
The document typically covers a range of important aspects, such as:
1. Scope of alterations: It specifies the nature and extent of alterations that the licensee is authorized to undertake, including any limitations or restrictions imposed by the licensor.
2. Compliance with laws and regulations: The template emphasizes the licensee's responsibility to comply with all applicable UK laws, regulations, and building codes throughout the alteration process.
3. Permissions and permits: It may detail any necessary permits or permissions that the licensee must obtain from local authorities or other relevant bodies prior to commencing the alterations.
4. Timeframe and completion: The template may include provisions regarding the anticipated timeframe for completing the alterations and any penalties or repercussions for delays or failure to complete within the agreed-upon timeframe.
5. Costs and financial obligations: This section outlines the financial aspects of the license agreement, including any associated costs, fees, or charges to be borne by the licensee, as well as any indemnification clauses to protect the licensor against potential costs or damages.
6. Insurance and liability: The template may specify the insurance requirements the licensee must meet to protect against potential damages or accidents during the alteration process. It may also address liability for any damages caused by the licensee or their contractors.
7. Termination and dispute resolution: The document may outline the circumstances under which either party can terminate the license agreement, as well as the methods by which disputes will be resolved, such as through negotiation, mediation, or legal action.
It's important to note that this is a general description, and the specific content and provisions within the template can vary depending on the purpose, nature of alterations, and individual preferences of the parties involved.
The template serves as a contractual framework between the property owner, referred to as the licensor, and the individual or entity seeking permission to carry out alterations, referred to as the licensee. It sets out the general terms under which the licensee can proceed with the proposed alterations, ensuring the licensor's interests are protected and the alterations comply with relevant legal and regulatory standards.
The document typically covers a range of important aspects, such as:
1. Scope of alterations: It specifies the nature and extent of alterations that the licensee is authorized to undertake, including any limitations or restrictions imposed by the licensor.
2. Compliance with laws and regulations: The template emphasizes the licensee's responsibility to comply with all applicable UK laws, regulations, and building codes throughout the alteration process.
3. Permissions and permits: It may detail any necessary permits or permissions that the licensee must obtain from local authorities or other relevant bodies prior to commencing the alterations.
4. Timeframe and completion: The template may include provisions regarding the anticipated timeframe for completing the alterations and any penalties or repercussions for delays or failure to complete within the agreed-upon timeframe.
5. Costs and financial obligations: This section outlines the financial aspects of the license agreement, including any associated costs, fees, or charges to be borne by the licensee, as well as any indemnification clauses to protect the licensor against potential costs or damages.
6. Insurance and liability: The template may specify the insurance requirements the licensee must meet to protect against potential damages or accidents during the alteration process. It may also address liability for any damages caused by the licensee or their contractors.
7. Termination and dispute resolution: The document may outline the circumstances under which either party can terminate the license agreement, as well as the methods by which disputes will be resolved, such as through negotiation, mediation, or legal action.
It's important to note that this is a general description, and the specific content and provisions within the template can vary depending on the purpose, nature of alterations, and individual preferences of the parties involved.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Witness Statement Supporting Application Of Enforcement of Adjudication
This legal template is designed to assist individuals or businesses applying for the enforcement of an adjudication decision under UK law. An adjudication decision is a binding decision made by an adjudicator, typically appointed to resolve disputes related to construction projects or other contractual matters.
The template provides a structure for a witness statement, which is a written account of facts and evidence that a witness must provide to support the application for enforcement. This statement typically outlines the witness's knowledge, involvement, or observations related to the dispute and the adjudication process.
The purpose of this template is to ensure that the witness statement is organized, comprehensive, and aligned with the requirements set forth by UK law. It may include sections to summarize the witness's background, their relationship with the parties involved, detailed chronology of events leading to the dispute, and specific details about the adjudication procedure, including any relevant documents or correspondence.
By using this template, applicants can provide a well-structured witness statement that strengthens their case for the enforcement of the adjudication decision. It helps maintain consistency and clarity in the legal document, thereby increasing the chance of a successful outcome in the enforcement proceedings.
The template provides a structure for a witness statement, which is a written account of facts and evidence that a witness must provide to support the application for enforcement. This statement typically outlines the witness's knowledge, involvement, or observations related to the dispute and the adjudication process.
The purpose of this template is to ensure that the witness statement is organized, comprehensive, and aligned with the requirements set forth by UK law. It may include sections to summarize the witness's background, their relationship with the parties involved, detailed chronology of events leading to the dispute, and specific details about the adjudication procedure, including any relevant documents or correspondence.
By using this template, applicants can provide a well-structured witness statement that strengthens their case for the enforcement of the adjudication decision. It helps maintain consistency and clarity in the legal document, thereby increasing the chance of a successful outcome in the enforcement proceedings.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
1
DISCUSSIONS
2
Withholding Notice (Construction Contract)
The Withholding Notice (Construction Contract) legal template under UK law is a document used in the construction industry to provide formal notification of withholding payment to a contractor or subcontractor. This template is typically utilized when there are legitimate concerns or disputes regarding the quality of work, completion delays, breach of contract, or any other contractual issues that justify withholding payment.
The template outlines the relevant details such as project information, parties involved, and the specific reasons for withholding payment. It incorporates the necessary legal language and provisions required by UK law to ensure compliance and protection of both parties' rights. Additionally, it may include the amount being withheld, the date the notice is being issued, and any applicable deadlines for rectifying the mentioned issues.
By using this template, it allows the withholding party to communicate their concerns clearly and formally to the contractor, highlighting any breach or non-compliance that has occurred under the construction contract. This document serves as a vital tool in resolving disputes and initiating discussions for potential resolution prior to progressing to more formal legal actions or arbitration.
It is important to note that the Withholding Notice (Construction Contract) template under UK law should be reviewed by legal professionals who are specialized in construction law or litigation to ensure its suitability and compliance with the specific circumstances and jurisdiction.
The template outlines the relevant details such as project information, parties involved, and the specific reasons for withholding payment. It incorporates the necessary legal language and provisions required by UK law to ensure compliance and protection of both parties' rights. Additionally, it may include the amount being withheld, the date the notice is being issued, and any applicable deadlines for rectifying the mentioned issues.
By using this template, it allows the withholding party to communicate their concerns clearly and formally to the contractor, highlighting any breach or non-compliance that has occurred under the construction contract. This document serves as a vital tool in resolving disputes and initiating discussions for potential resolution prior to progressing to more formal legal actions or arbitration.
It is important to note that the Withholding Notice (Construction Contract) template under UK law should be reviewed by legal professionals who are specialized in construction law or litigation to ensure its suitability and compliance with the specific circumstances and jurisdiction.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
3
RATINGS
3
DISCUSSIONS
0
Witness Statement In Opposition To Summary Judgment Application
This legal template is a document that allows an individual, often referred to as the witness, to provide their statement and arguments opposing a summary judgment application under UK law. Summary judgment is a legal procedure used to promptly resolve a case by determining whether there is any genuine issue to be tried or if the opposing party has a valid defense or claim. In this template, the witness can outline their evidence, arguments, and any relevant facts that support their opposition to the summary judgment application. The template is tailored specifically for the legal system in the United Kingdom and aims to assist individuals in presenting a comprehensive and compelling case against the granting of summary judgment.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
0
DISCUSSIONS
2
