All Templates
Sell or outsource software development
🧑💻 Software development agreement
Software Development Agreement (Pro-Supplier)
Software Development Agreement (Pro-Supplier)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useContract party
Relevant sectors
Type of legal document
🧑💻 Software development agreementBusiness activity
Sell or outsource software developmentA software development agreement is a contract between a software developer and a client that outlines the terms of the software development project. The agreement should include a description of the project, the roles and responsibilities of each party, the schedule and milestones, and the payment terms. The agreement should also address intellectual property ownership, confidentiality, and other legal issues.
The Software Development Agreement (Pro-Supplier) under UK law is a comprehensive legal template that governs the contractual relationship between a software development supplier and their client. This agreement sets out the terms and conditions that both parties must abide by throughout the software development process.
Primarily, this agreement focuses on protecting the rights and interests of the software development supplier. It outlines the scope of work, deliverables, and timelines agreed upon between the parties. The template also emphasizes intellectual property rights, stating that the supplier will retain ownership of any software developed unless otherwise agreed. It may include provisions for granting the client a license to use the software upon successful completion.
Additionally, the agreement addresses payment terms, including the amount and schedule of payments to be made by the client to the supplier. It may incorporate clauses to account for any change requests or additional work, establishing mechanisms to address such modifications to the original scope.
Confidentiality and data protection are paramount in this template, ensuring the supplier's trade secrets and the client's sensitive information remain secure. The agreement may impose obligations on both parties to maintain confidentiality and handle data in accordance with applicable laws and regulations.
Furthermore, the agreement may cover liability and indemnity provisions, allocating responsibility between the parties in the event of errors, delays, or breaches. It may include dispute resolution mechanisms such as mediation or arbitration, providing a structured process to address any conflicts that may arise.
Overall, the Software Development Agreement (Pro-Supplier) under UK law serves to establish a fair and balanced partnership between software development suppliers and their clients, ensuring both parties' interests are safeguarded while enabling the successful completion of software projects.
Primarily, this agreement focuses on protecting the rights and interests of the software development supplier. It outlines the scope of work, deliverables, and timelines agreed upon between the parties. The template also emphasizes intellectual property rights, stating that the supplier will retain ownership of any software developed unless otherwise agreed. It may include provisions for granting the client a license to use the software upon successful completion.
Additionally, the agreement addresses payment terms, including the amount and schedule of payments to be made by the client to the supplier. It may incorporate clauses to account for any change requests or additional work, establishing mechanisms to address such modifications to the original scope.
Confidentiality and data protection are paramount in this template, ensuring the supplier's trade secrets and the client's sensitive information remain secure. The agreement may impose obligations on both parties to maintain confidentiality and handle data in accordance with applicable laws and regulations.
Furthermore, the agreement may cover liability and indemnity provisions, allocating responsibility between the parties in the event of errors, delays, or breaches. It may include dispute resolution mechanisms such as mediation or arbitration, providing a structured process to address any conflicts that may arise.
Overall, the Software Development Agreement (Pro-Supplier) under UK law serves to establish a fair and balanced partnership between software development suppliers and their clients, ensuring both parties' interests are safeguarded while enabling the successful completion of software projects.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Section 247 Notice Of Stopping Up Order
The legal template titled "Section 247 Notice Of Stopping Up Order under UK law" likely pertains to a process regulated by Section 247 of the Town and Country Planning Act 1990 in the United Kingdom. This law addresses the stopping up (closing or blocking) of highways or public rights of way to enable development projects or infrastructure works.
The template could serve as a formal legal notice issued by a local planning authority (such as a local council or government agency) to inform interested parties of their intention to make a "Stopping Up Order" under Section 247. The purpose of this order would be to legally stop up or close a specific highway or public right of way, permitting an upcoming construction project or land development.
The notice could contain vital information such as the name and contact details of the local planning authority, a description and location of the highway or public right of way to be stopped up, the proposed order and its effect, relevant dates, and any procedures for objections or representations from interested parties.
By providing details about the potential stopping up of a roadway or public access point, this legal template plays a crucial role in ensuring transparency and giving affected individuals, such as neighboring landowners, local residents, and other stakeholders, an opportunity to voice their concerns or object to the proposed order.
The template could serve as a formal legal notice issued by a local planning authority (such as a local council or government agency) to inform interested parties of their intention to make a "Stopping Up Order" under Section 247. The purpose of this order would be to legally stop up or close a specific highway or public right of way, permitting an upcoming construction project or land development.
The notice could contain vital information such as the name and contact details of the local planning authority, a description and location of the highway or public right of way to be stopped up, the proposed order and its effect, relevant dates, and any procedures for objections or representations from interested parties.
By providing details about the potential stopping up of a roadway or public access point, this legal template plays a crucial role in ensuring transparency and giving affected individuals, such as neighboring landowners, local residents, and other stakeholders, an opportunity to voice their concerns or object to the proposed order.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
2
DISCUSSIONS
1
Section 479 Subsidiary Company Audit Exemption
This legal template could be a document that provides guidance and instructions on the audit exemption criteria for subsidiary companies under UK law. It may outline the specific provisions and requirements mandated by Section 479 of the UK Companies Act, which allow qualifying subsidiaries to be exempt from the statutory auditing obligations.
The template may further explain the eligibility criteria that a subsidiary company must meet to avail themselves of the audit exemption, such as requirements related to size, shareholding, and group structures. It might also provide instructions on the filing and reporting obligations that the subsidiary company would still need to fulfill despite the exemption.
Additionally, the template may outline the consequences and potential penalties for non-compliance with the applicable regulations, emphasizing the importance of maintaining accurate financial records and ensuring compliance with any disclosure requirements.
Overall, this legal template would serve as a comprehensive guide for subsidiary companies operating in the UK, offering guidance on the audit exemption provision to facilitate compliance with the law and streamline their financial reporting processes.
The template may further explain the eligibility criteria that a subsidiary company must meet to avail themselves of the audit exemption, such as requirements related to size, shareholding, and group structures. It might also provide instructions on the filing and reporting obligations that the subsidiary company would still need to fulfill despite the exemption.
Additionally, the template may outline the consequences and potential penalties for non-compliance with the applicable regulations, emphasizing the importance of maintaining accurate financial records and ensuring compliance with any disclosure requirements.
Overall, this legal template would serve as a comprehensive guide for subsidiary companies operating in the UK, offering guidance on the audit exemption provision to facilitate compliance with the law and streamline their financial reporting processes.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
2
RATINGS
1
DISCUSSIONS
1
Section 127 Validation Order Application Notice
The legal template for a Section 127 Validation Order Application Notice under UK law is a document used to apply for a validation order from the court. Section 127 of the Insolvency Act 1986 states that certain transactions entered into by a company may be voidable if they were made to defraud creditors or are deemed at an undervalue. A validation order seeks to confirm the validity of such transactions and protect them from being challenged under this section of the law.
The application notice is typically filed by a company or an interested party who wishes to provide legal certainty and protection to a particular transaction or series of transactions. The notice will outline the relevant details and parties involved, describe the nature and purpose of the transactions, and provide evidence or arguments supporting the request for validation.
The template may include sections such as the title of the proceedings, the court and relevant parties' names, and contact information. It will also contain a statement of the grounds upon which the application is made, including any legal authorities or precedent relied upon. Additionally, the template will likely provide sections to state the precise relief sought, any relevant material facts, and provide supporting documents or witness statements as necessary.
By utilizing this template, individuals or companies seeking legal protection for their transactions can efficiently draft and submit an application notice for a Section 127 Validation Order to the UK court.
The application notice is typically filed by a company or an interested party who wishes to provide legal certainty and protection to a particular transaction or series of transactions. The notice will outline the relevant details and parties involved, describe the nature and purpose of the transactions, and provide evidence or arguments supporting the request for validation.
The template may include sections such as the title of the proceedings, the court and relevant parties' names, and contact information. It will also contain a statement of the grounds upon which the application is made, including any legal authorities or precedent relied upon. Additionally, the template will likely provide sections to state the precise relief sought, any relevant material facts, and provide supporting documents or witness statements as necessary.
By utilizing this template, individuals or companies seeking legal protection for their transactions can efficiently draft and submit an application notice for a Section 127 Validation Order to the UK court.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
1
DISCUSSIONS
1
