All Templates
Send default notice
📄 Section 278 agreement
Section 278 Agreement: Notice Of Default (Council To Developer)
Section 278 Agreement: Notice Of Default (Council To Developer)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
📄 Section 278 agreementBusiness activity
Send default noticeThe Section 278 Agreement: Notice Of Default (Council To Developer) under UK law is a legal template that outlines the procedure and requirements for notifying a developer of default under a Section 278 Agreement. Section 278 Agreements are typically entered into between a local authority (council) and a developer for the purpose of facilitating necessary highway works that are related to a development project.
This template provides the necessary framework for the local authority to formally notify the developer when they are in breach of their obligations or have failed to adhere to the terms outlined in the Section 278 Agreement. The notice of default serves as a formal communication, triggering certain legal consequences to rectify the default and ensuring the progress of the development project.
The agreement may specify different types of defaults, such as failure to complete works within the agreed timeframe, failure to provide required documentation, financial defaults, or non-compliance with relevant regulations. The notice of default describes the specific nature of the breach, the corresponding clause or provision of the Section 278 Agreement that has been violated, and the necessary steps to rectify the default.
The template also highlights the potential consequences of the default, which could include financial penalties, suspension of the development project, or even termination of the Section 278 Agreement. It may also outline the dispute resolution process in case the developer wishes to contest the notice of default or negotiate alternative solutions.
This legal template is designed to provide clarity, structure, and consistency in addressing defaults under a Section 278 Agreement, ensuring that both parties are aware of their rights, obligations, and the necessary steps to remedy any breach. It is intended to serve as a guide for local authorities in maintaining accountability and enforcing compliance with the terms of the agreement between the council and the developer.
This template provides the necessary framework for the local authority to formally notify the developer when they are in breach of their obligations or have failed to adhere to the terms outlined in the Section 278 Agreement. The notice of default serves as a formal communication, triggering certain legal consequences to rectify the default and ensuring the progress of the development project.
The agreement may specify different types of defaults, such as failure to complete works within the agreed timeframe, failure to provide required documentation, financial defaults, or non-compliance with relevant regulations. The notice of default describes the specific nature of the breach, the corresponding clause or provision of the Section 278 Agreement that has been violated, and the necessary steps to rectify the default.
The template also highlights the potential consequences of the default, which could include financial penalties, suspension of the development project, or even termination of the Section 278 Agreement. It may also outline the dispute resolution process in case the developer wishes to contest the notice of default or negotiate alternative solutions.
This legal template is designed to provide clarity, structure, and consistency in addressing defaults under a Section 278 Agreement, ensuring that both parties are aware of their rights, obligations, and the necessary steps to remedy any breach. It is intended to serve as a guide for local authorities in maintaining accountability and enforcing compliance with the terms of the agreement between the council and the developer.
How it works
Create doc / use template
Chat to our AI Legal Assistant
Edit, collaborate & share
Export to .docx
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Statement of Ethics boilerplate (Bribery Act 2010)
The Statement of Ethics boilerplate (Bribery Act 2010) under UK law is a legal template that outlines the ethical standards and policies of an organization in relation to anti-bribery measures. The document provides guidance on the expectations, responsibilities, and consequences of bribery within the business.
The template is in accordance with the Bribery Act 2010, a UK legislation aimed at combating bribery and corruption in both public and private sectors. It serves as a proactive tool for organizations to establish and communicate their commitment to ethical business practices, ensuring compliance with the law and promoting a culture of integrity.
The Statement of Ethics boilerplate typically covers various aspects, including definitions of bribery and associated offenses, guidelines for employees, agents, and third parties, procedures for reporting suspicions or incidents of bribery, consequences for violating the policy, and measures for preventing and detecting bribery activities within the company.
Customizable to suit the specific needs and nature of the organization, the template provides a starting point for businesses to develop their own comprehensive Statement of Ethics. By adopting this boilerplate, companies can reinforce their commitment to ethical conduct, promote transparency, and safeguard their reputation while complying with the Bribery Act 2010.
The template is in accordance with the Bribery Act 2010, a UK legislation aimed at combating bribery and corruption in both public and private sectors. It serves as a proactive tool for organizations to establish and communicate their commitment to ethical business practices, ensuring compliance with the law and promoting a culture of integrity.
The Statement of Ethics boilerplate typically covers various aspects, including definitions of bribery and associated offenses, guidelines for employees, agents, and third parties, procedures for reporting suspicions or incidents of bribery, consequences for violating the policy, and measures for preventing and detecting bribery activities within the company.
Customizable to suit the specific needs and nature of the organization, the template provides a starting point for businesses to develop their own comprehensive Statement of Ethics. By adopting this boilerplate, companies can reinforce their commitment to ethical conduct, promote transparency, and safeguard their reputation while complying with the Bribery Act 2010.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
2
RATINGS
1
DISCUSSIONS
1
Standard Wording For Et1 (Sex Discrimination And Unfair Dismissal)
This legal template, titled "Standard Wording For ET1 (Sex Discrimination And Unfair Dismissal) under UK law," is a standardized draft document designed to assist claimants in lodging their complaints with an Employment Tribunal (ET) in the United Kingdom.
The template primarily focuses on claims related to sex discrimination and unfair dismissal, two significant areas of employment law violations. It provides a structured format and pre-drafted language that claimants can use as a foundation while submitting their ET1 form – an initial document initiating the employment tribunal process.
Within this legal template, claimants can expect to find sections covering various critical aspects, such as their personal details, the respondent's (the employer) information, a detailed narrative outlining the circumstances of the case, relevant legal grounds for the complaint (specifically pertaining to sex discrimination and unfair dismissal), and any supporting evidence or witnesses involved. The wording within the template would be concise, clear, and align with the legal standards required by UK law.
While this template aims to provide a starting point, claimants should be aware that it may require customization to fit their specific circumstances and provide accurate details. Consulting with a legal professional or an employment law advisor is advisable before submitting the ET1 form to ensure a strong and effective case is presented to the Employment Tribunal.
The template primarily focuses on claims related to sex discrimination and unfair dismissal, two significant areas of employment law violations. It provides a structured format and pre-drafted language that claimants can use as a foundation while submitting their ET1 form – an initial document initiating the employment tribunal process.
Within this legal template, claimants can expect to find sections covering various critical aspects, such as their personal details, the respondent's (the employer) information, a detailed narrative outlining the circumstances of the case, relevant legal grounds for the complaint (specifically pertaining to sex discrimination and unfair dismissal), and any supporting evidence or witnesses involved. The wording within the template would be concise, clear, and align with the legal standards required by UK law.
While this template aims to provide a starting point, claimants should be aware that it may require customization to fit their specific circumstances and provide accurate details. Consulting with a legal professional or an employment law advisor is advisable before submitting the ET1 form to ensure a strong and effective case is presented to the Employment Tribunal.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
4
DISCUSSIONS
2
Standard Services Agreement
A Standard Services Agreement under UK law is a legal template that outlines the terms and conditions governing the provision and receipt of services between a service provider and a client or customer. This agreement is specifically designed to comply with the legal requirements and regulations of the United Kingdom and is tailored to serve as a foundation for any type of service-related business or industry.
The agreement covers crucial aspects such as the scope of services, payment terms, delivery timelines, intellectual property rights, confidentiality, liability limitations, termination rights, and dispute resolution mechanisms. It aims to establish a clear understanding between the parties involved, ensuring that both the service provider and the client are on the same page regarding their respective obligations and expectations.
By utilizing this Standard Services Agreement, businesses or individuals can save time and effort in drafting a customized contract from scratch. The template provides a solid framework that can be further modified or personalized to suit the specific needs and requirements of the parties involved. It serves as a legally binding document that protects the interests of both parties and provides a clear and enforceable framework for the provision of services in compliance with UK law.
The agreement covers crucial aspects such as the scope of services, payment terms, delivery timelines, intellectual property rights, confidentiality, liability limitations, termination rights, and dispute resolution mechanisms. It aims to establish a clear understanding between the parties involved, ensuring that both the service provider and the client are on the same page regarding their respective obligations and expectations.
By utilizing this Standard Services Agreement, businesses or individuals can save time and effort in drafting a customized contract from scratch. The template provides a solid framework that can be further modified or personalized to suit the specific needs and requirements of the parties involved. It serves as a legally binding document that protects the interests of both parties and provides a clear and enforceable framework for the provision of services in compliance with UK law.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
3
DISCUSSIONS
2
