All Templates
Vary completion date
🏚️ Completion date variation
Property Completion Date Variation Agreement
Property Completion Date Variation Agreement
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Completion date variationBusiness activity
Vary completion dateA completion date variation is a change to the date that is specified in the contract for the project to be completed. This could be due to a number of reasons such as delays in the construction process. The completion date variation will usually result in an extension of time being granted to the contractor.
This legal template, the Property Completion Date Variation Agreement, is a document specifically designed to address modifications to the agreed completion date of a property transaction under the jurisdiction of UK law. In real estate transactions, there can be circumstances where unforeseen events or issues arise, causing delays in the original completion date stated in the initial agreement. This template serves as a formal contract between the parties involved, allowing them to mutually agree on a revised completion date.
The Property Completion Date Variation Agreement template comprises various clauses and sections, articulating the terms and conditions agreed upon by both the buyer and seller. These provisions typically cover crucial aspects such as the reason for the alteration, the new completion date, any associated penalties or costs resulting from the delay, and the obligations and liabilities of each party.
By utilizing this legally binding document, both the buyer and seller can ensure clarity regarding the revised timeframe for transferring ownership of the property. The template aims to protect the interests of all parties involved by outlining the adjustments necessary to accommodate the current circumstances and avoid any potential disputes or misunderstandings.
It is important to note that this legal template may be adapted to suit the specific requirements of the parties involved, and should ideally be drafted or reviewed by an experienced solicitor or legal professional well-versed in property law in the United Kingdom.
The Property Completion Date Variation Agreement template comprises various clauses and sections, articulating the terms and conditions agreed upon by both the buyer and seller. These provisions typically cover crucial aspects such as the reason for the alteration, the new completion date, any associated penalties or costs resulting from the delay, and the obligations and liabilities of each party.
By utilizing this legally binding document, both the buyer and seller can ensure clarity regarding the revised timeframe for transferring ownership of the property. The template aims to protect the interests of all parties involved by outlining the adjustments necessary to accommodate the current circumstances and avoid any potential disputes or misunderstandings.
It is important to note that this legal template may be adapted to suit the specific requirements of the parties involved, and should ideally be drafted or reviewed by an experienced solicitor or legal professional well-versed in property law in the United Kingdom.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Scott Schedule Delay and Disruption Claim
The Scott Schedule Delay and Disruption Claim template is a legal document specifically designed to streamline and organize the process of making a claim for delay and disruption in a construction project under the jurisdiction of UK law.
Featuring a structured layout, the template allows for a systematic presentation of relevant information, facilitating effective communication between the parties involved. It provides sections to outline the project details, contractual terms, and the specific events or circumstances that have caused delay or disruption.
Furthermore, the template incorporates a detailed timeline, enabling users to clearly demonstrate the project schedule before and after the alleged delay or disruption, reinforcing the claim's validity. It also includes sections to assert the alleged consequences, such as increased costs, loss of productivity, or project stalling, which can be substantiated with supporting evidence.
Additionally, the template accommodates the inclusion of any applicable laws, contracts, or regulations pertinent to the claim. By utilizing this template, claimants can present their case in a structured and comprehensive manner, streamlining the claims process and increasing the chances of a successful resolution under UK legal standards.
Featuring a structured layout, the template allows for a systematic presentation of relevant information, facilitating effective communication between the parties involved. It provides sections to outline the project details, contractual terms, and the specific events or circumstances that have caused delay or disruption.
Furthermore, the template incorporates a detailed timeline, enabling users to clearly demonstrate the project schedule before and after the alleged delay or disruption, reinforcing the claim's validity. It also includes sections to assert the alleged consequences, such as increased costs, loss of productivity, or project stalling, which can be substantiated with supporting evidence.
Additionally, the template accommodates the inclusion of any applicable laws, contracts, or regulations pertinent to the claim. By utilizing this template, claimants can present their case in a structured and comprehensive manner, streamlining the claims process and increasing the chances of a successful resolution under UK legal standards.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
6
RATINGS
2
DISCUSSIONS
1
Section 10 Lapse of Offer Notice
This legal template, titled "Section 10 Lapse of Offer Notice under UK law," likely relates to a specific provision in English contract law. Section 10 of the English Contract Act addresses circumstances in which an offer made by one party can become void or "lapse" under certain conditions. The template is likely designed to outline the notice that a party must provide to the offeror regarding the termination or expiration of an offer, as required by UK law. It may detail the specific information that must be included in the notice, the method of delivery, and any relevant timelines or deadlines to comply with legal requirements. This template could be used by solicitors, legal professionals, or individuals engaging in contract negotiations to ensure that they adhere to the proper procedures outlined in Section 10 of UK law when an offer lapses.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
2
RATINGS
3
DISCUSSIONS
2
Rule 71 Employment Tribunal Application For A Reconsideration Of Judgment
The legal template "Rule 71 Employment Tribunal Application For A Reconsideration Of Judgment under UK law" outlines the process and procedure for an individual or company seeking to request a reconsideration of a judgment previously made by an Employment Tribunal in the United Kingdom.
Employment Tribunals are judicial bodies responsible for resolving disputes between employers and employees related to employment rights, discrimination, unfair dismissals, wages, and other employment-related matters. In certain cases, a party may believe that the initial judgment made by the Employment Tribunal was incorrect, unfair, or overlooked specific evidence or legal arguments.
The template, based on Rule 71 of the UK Employment Tribunal Rules of Procedure, provides a structured framework for filing an application to request the Employment Tribunal to reconsider its judgment. It includes the necessary information and legal grounds to support the application, such as identifying the parties involved, providing a clear timeline of events, explaining the reasons for disagreement with the initial judgment, and citing relevant laws or legal precedents to support the request.
The purpose of this legal template is to assist individuals or organizations in preparing and submitting a formal application for reconsideration, ensuring that all necessary information is included and all legal requirements are met. By following this template, applicants can present their case effectively to the Employment Tribunal, providing compelling arguments for why the judgment should be reconsidered in light of new evidence, legal errors, or other relevant factors.
It is essential to note that this template is not intended as legal advice, but rather as a starting point for individuals or legal professionals to draft an application for reconsideration effectively. Understanding and complying with the specific requirements of the Employment Tribunal and UK employment law are critical to ensuring a proper and successful application. Therefore, seeking the guidance of experienced employment law specialists is advised to ensure the best possible outcome in this complex legal process.
Employment Tribunals are judicial bodies responsible for resolving disputes between employers and employees related to employment rights, discrimination, unfair dismissals, wages, and other employment-related matters. In certain cases, a party may believe that the initial judgment made by the Employment Tribunal was incorrect, unfair, or overlooked specific evidence or legal arguments.
The template, based on Rule 71 of the UK Employment Tribunal Rules of Procedure, provides a structured framework for filing an application to request the Employment Tribunal to reconsider its judgment. It includes the necessary information and legal grounds to support the application, such as identifying the parties involved, providing a clear timeline of events, explaining the reasons for disagreement with the initial judgment, and citing relevant laws or legal precedents to support the request.
The purpose of this legal template is to assist individuals or organizations in preparing and submitting a formal application for reconsideration, ensuring that all necessary information is included and all legal requirements are met. By following this template, applicants can present their case effectively to the Employment Tribunal, providing compelling arguments for why the judgment should be reconsidered in light of new evidence, legal errors, or other relevant factors.
It is essential to note that this template is not intended as legal advice, but rather as a starting point for individuals or legal professionals to draft an application for reconsideration effectively. Understanding and complying with the specific requirements of the Employment Tribunal and UK employment law are critical to ensuring a proper and successful application. Therefore, seeking the guidance of experienced employment law specialists is advised to ensure the best possible outcome in this complex legal process.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
6
RATINGS
5
DISCUSSIONS
3
