Property Completion Date Variation Agreement
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Completion date variationBusiness activity
Vary completion dateA completion date variation is a change to the date that is specified in the contract for the project to be completed. This could be due to a number of reasons such as delays in the construction process. The completion date variation will usually result in an extension of time being granted to the contractor.
The Property Completion Date Variation Agreement template comprises various clauses and sections, articulating the terms and conditions agreed upon by both the buyer and seller. These provisions typically cover crucial aspects such as the reason for the alteration, the new completion date, any associated penalties or costs resulting from the delay, and the obligations and liabilities of each party.
By utilizing this legally binding document, both the buyer and seller can ensure clarity regarding the revised timeframe for transferring ownership of the property. The template aims to protect the interests of all parties involved by outlining the adjustments necessary to accommodate the current circumstances and avoid any potential disputes or misunderstandings.
It is important to note that this legal template may be adapted to suit the specific requirements of the parties involved, and should ideally be drafted or reviewed by an experienced solicitor or legal professional well-versed in property law in the United Kingdom.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Secured Facility Agreement For Management Buyouts
This legal template is specifically designed to address the financial aspect of such a transaction, specifically focusing on the provision of funds by a third-party lender to support the management buyout. The agreement will commonly include provisions related to the loan amount, interest rates, repayment terms, collateral requirements, and any warranties or representations made by the management team regarding the operation and viability of the business.
Under UK law, this agreement is intended to ensure that all parties involved in the management buyout, including the lender, management team, and existing shareholders, have a clear understanding of their rights, obligations, and responsibilities. It establishes the terms of the loan, secures the investment against predetermined assets or collateral, and provides a legal framework for resolving any potential disputes that may arise during the transaction process.
Overall, this legal template serves as a comprehensive and legally binding document to govern the financial relationship between the lender and the management team during a management buyout under UK law.
Publisher
Genie AIJurisdiction
England and WalesServices Consultant Contract
This Services Consultant contract template is designed for a commercial services consulting organisation (or an individual services consultant) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of services consulting and services-consulting-related services to be completed by the services consultant on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the services consulting firm or individual services consultant on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
Publisher
Genie AIJurisdiction
England and WalesSection 284 Void Disposition Application Notice
The template would provide a comprehensive structure to draft such an application notice, including the necessary details and legal arguments to support the request for the declaration of void disposition. It may require the applicant to outline the specific circumstances surrounding the transaction, such as the timing, nature, and purpose of the disposition, as well as any evidence or factual basis supporting the claim of its invalidity.
Additionally, the template may include information on the relevant legal provisions under Section 284, highlighting the key requirements and legal tests that need to be met to succeed in obtaining a declaration of void disposition. It could also provide guidance on the appropriate remedies sought and any specific orders that can be requested from the court.
Overall, the Section 284 Void Disposition Application Notice template aims to assist legal professionals or individuals in preparing a thorough and well-structured application to challenge a potentially fraudulent or detrimental transaction, ensuring that all necessary information and legal arguments are properly presented to maximize the chances of success in court.
