Property Completion Date Variation Agreement
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Completion date variationBusiness activity
Vary completion dateA completion date variation is a change to the date that is specified in the contract for the project to be completed. This could be due to a number of reasons such as delays in the construction process. The completion date variation will usually result in an extension of time being granted to the contractor.
The Property Completion Date Variation Agreement template comprises various clauses and sections, articulating the terms and conditions agreed upon by both the buyer and seller. These provisions typically cover crucial aspects such as the reason for the alteration, the new completion date, any associated penalties or costs resulting from the delay, and the obligations and liabilities of each party.
By utilizing this legally binding document, both the buyer and seller can ensure clarity regarding the revised timeframe for transferring ownership of the property. The template aims to protect the interests of all parties involved by outlining the adjustments necessary to accommodate the current circumstances and avoid any potential disputes or misunderstandings.
It is important to note that this legal template may be adapted to suit the specific requirements of the parties involved, and should ideally be drafted or reviewed by an experienced solicitor or legal professional well-versed in property law in the United Kingdom.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Section 643 Standard Statement Of Solvency (Reducing Capital)
The template assists companies in preparing a statement of solvency, which is a crucial document confirming that the company's assets exceed its liabilities after the proposed reduction of share capital. The statement of solvency must be signed by the company's directors and include relevant financial information, supporting the company's ability to meet its existing and future obligations post-reduction.
By using this legal template, companies can effectively navigate the legal procedures involved in reducing capital, safeguarding the interests of stakeholders and ensuring compliance with the Companies Act. It provides structure and assists in organizing the necessary information, ensuring that all required details are accurately captured within the statement of solvency.
Publisher
Genie AIJurisdiction
England and WalesSecurity Guard Contract
This Security Guard contract template is designed for a commercial security organisation (or an individual security guard) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of security and security-related services to be completed by the security guard on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the security firm or individual security guard on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
Publisher
Genie AIJurisdiction
England and WalesSettlement Agreement Offer Letter (Following Protected Conversation Pre-Termination)
In the United Kingdom, employers may engage in a "protected conversation" with an employee to discuss certain matters related to the termination of their employment, without the risk of these conversations being used as evidence in an employment tribunal. This legal template specifically applies to situations where the employer wishes to propose a settlement agreement as an alternative to termination.
The Settlement Agreement Offer Letter serves as a formal communication from the employer to the employee, presenting the proposed terms of the settlement agreement, including financial compensation, benefits, and other relevant terms. It aims to outline a fair and mutually agreeable resolution, addressing any potential disputes or claims that may arise from the termination of employment.
This legal document typically includes sections covering the background of the protected conversations, the reasons for considering a settlement agreement, the terms and conditions being offered, any special conditions or restrictions, the timeline for response and negotiation, as well as the potential consequences of not accepting the offer. It will reference the relevant legal provisions under UK law, ensuring compliance and clarity in the document.
The Settlement Agreement Offer Letter is an essential step in initiating settlement discussions, encouraging open dialogue between employers and employees in an attempt to reach a mutually beneficial outcome, while protecting both parties' interests. It offers an opportunity for the employer and employee to negotiate and potentially avoid the time, expense, and uncertainty associated with taking the matter to an employment tribunal.
