Pay Less Notice (Construction Contract)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Pay less noticeBusiness activity
Pay less noticeA pay less notice is a notice served by a contractor to a sub-contractor that sets out the sum the contractor considers to be due under the sub-contract. The notice must be served before the final date for payment stated in the sub-contract. If the sub-contractor does not agree with the sum stated in the pay less notice, they can serve a notice of intention to withhold payment.
The Pay Less Notice (Construction Contract) is a legal template commonly used in the United Kingdom within the construction industry. This document serves as a formal notice to the contractor from the employer, highlighting the intention to pay an amount less than the sum usually invoiced for the completed work or ongoing project.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Unfair Dismissal (Advice To Employee Client Considering Claim)
The legal template on "Unfair Dismissal (Advice To Employee Client Considering Claim) under UK law" is a document intended to guide legal professionals in providing advice to an employee who is contemplating pursuing a claim for unfair dismissal in the United Kingdom.
The template likely includes sections addressing the relevant legal framework surrounding unfair dismissal, which is primarily governed by the Employment Rights Act 1996. It may provide an overview of the legal definition of unfair dismissal, criteria that must be satisfied to bring a claim, and various types of dismissal that may be considered unfair.
Furthermore, the template might outline the potential remedies available to the employee if their claim for unfair dismissal is successful, such as reinstatement or financial compensation. This section may also highlight the applicable time limits for bringing a claim and the process for initiating proceedings before an Employment Tribunal.
The template may further delve into the key grounds for a successful unfair dismissal claim, discussing common scenarios that may warrant such a claim, such as dismissal on discriminatory grounds, redundancy mismanagement, or a lack of sufficient disciplinary procedures. It might also offer guidance on gathering evidence to support the claimant's case, including witness statements, employee records, and relevant correspondence.
Additionally, the document could explore the importance of pursuing alternative dispute resolution methods, like mediation or negotiation, as a potential alternative to legal proceedings. It might provide advice on engaging in these discussions to explore potential settlement options for the dispute.
Overall, the template seeks to provide legal professionals with a comprehensive guide to advise their employee clients on the viability of pursuing an unfair dismissal claim in the United Kingdom and the various aspects they should consider before initiating legal action.
The template likely includes sections addressing the relevant legal framework surrounding unfair dismissal, which is primarily governed by the Employment Rights Act 1996. It may provide an overview of the legal definition of unfair dismissal, criteria that must be satisfied to bring a claim, and various types of dismissal that may be considered unfair.
Furthermore, the template might outline the potential remedies available to the employee if their claim for unfair dismissal is successful, such as reinstatement or financial compensation. This section may also highlight the applicable time limits for bringing a claim and the process for initiating proceedings before an Employment Tribunal.
The template may further delve into the key grounds for a successful unfair dismissal claim, discussing common scenarios that may warrant such a claim, such as dismissal on discriminatory grounds, redundancy mismanagement, or a lack of sufficient disciplinary procedures. It might also offer guidance on gathering evidence to support the claimant's case, including witness statements, employee records, and relevant correspondence.
Additionally, the document could explore the importance of pursuing alternative dispute resolution methods, like mediation or negotiation, as a potential alternative to legal proceedings. It might provide advice on engaging in these discussions to explore potential settlement options for the dispute.
Overall, the template seeks to provide legal professionals with a comprehensive guide to advise their employee clients on the viability of pursuing an unfair dismissal claim in the United Kingdom and the various aspects they should consider before initiating legal action.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
4
RATINGS
2
DISCUSSIONS
2
White Label Of Mobile Application (PaaS, Pro-Supplier)
This legal template is specifically designed for the white labeling of a mobile application under UK law.
White labeling refers to the process in which one company purchases a product or service from another company and then rebrands it as its own to sell or market it to its customers. In this case, the mobile application is being licensed or provided by a platform-as-a-service (PaaS) provider to a professional supplier.
The template would cover all the necessary legal aspects and terms that govern the relationship between the PaaS provider and the professional supplier. It would include clauses related to licensing the mobile application, intellectual property rights, usage restrictions, data protection and privacy, support and maintenance obligations, payment terms, liability and indemnification, termination conditions, and dispute resolution mechanisms.
Since this legal template is focused on UK law, it would also incorporate relevant legal requirements, such as compliance with UK data protection regulations (e.g., General Data Protection Regulation - GDPR), consumer protection laws, and any other applicable UK-specific regulations.
By utilizing this template, both the PaaS provider and the professional supplier would have a clear understanding of their rights, responsibilities, and obligations in regards to the white-labeled mobile application. It provides a legally sound and comprehensive agreement that protects the interests of both parties, ensuring a transparent and mutually beneficial partnership.
White labeling refers to the process in which one company purchases a product or service from another company and then rebrands it as its own to sell or market it to its customers. In this case, the mobile application is being licensed or provided by a platform-as-a-service (PaaS) provider to a professional supplier.
The template would cover all the necessary legal aspects and terms that govern the relationship between the PaaS provider and the professional supplier. It would include clauses related to licensing the mobile application, intellectual property rights, usage restrictions, data protection and privacy, support and maintenance obligations, payment terms, liability and indemnification, termination conditions, and dispute resolution mechanisms.
Since this legal template is focused on UK law, it would also incorporate relevant legal requirements, such as compliance with UK data protection regulations (e.g., General Data Protection Regulation - GDPR), consumer protection laws, and any other applicable UK-specific regulations.
By utilizing this template, both the PaaS provider and the professional supplier would have a clear understanding of their rights, responsibilities, and obligations in regards to the white-labeled mobile application. It provides a legally sound and comprehensive agreement that protects the interests of both parties, ensuring a transparent and mutually beneficial partnership.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
1
RATINGS
3
DISCUSSIONS
2
Written Tenancy Agreement Request (By Landlord or Tenant)
This legal template, titled "Written Tenancy Agreement Request (By Landlord or Tenant) under UK law," is a document that facilitates the formalization of a tenancy agreement between a landlord and tenant in the United Kingdom. The template can be utilized by either the landlord or the tenant, depending on who initiates the agreement request.
The purpose of this template is to provide a legally binding agreement that outlines the terms and conditions of the tenancy arrangement. It ensures that both parties have a clear understanding of their rights and responsibilities, minimizing potential disputes and protecting the interests of both the landlord and tenant.
The template covers key elements such as the property details, lease duration, rent payment terms, deposit requirements, maintenance responsibilities, utilities, and any further provisions or restrictions specific to the tenancy. It complies with the legal requirements set forth by UK law, ensuring that the agreement is legally valid and enforceable.
By utilizing this template, both the landlord and the tenant can rest assured that their rights and obligations are clearly defined. It provides a comprehensive framework to govern the landlord-tenant relationship, promoting transparency, stability, and effective communication throughout the tenancy period.
It is essential for both parties to carefully review and negotiate the terms of the agreement before signing. Additionally, it is advised to seek legal advice to ensure compliance with all applicable laws and regulations within the UK.
The purpose of this template is to provide a legally binding agreement that outlines the terms and conditions of the tenancy arrangement. It ensures that both parties have a clear understanding of their rights and responsibilities, minimizing potential disputes and protecting the interests of both the landlord and tenant.
The template covers key elements such as the property details, lease duration, rent payment terms, deposit requirements, maintenance responsibilities, utilities, and any further provisions or restrictions specific to the tenancy. It complies with the legal requirements set forth by UK law, ensuring that the agreement is legally valid and enforceable.
By utilizing this template, both the landlord and the tenant can rest assured that their rights and obligations are clearly defined. It provides a comprehensive framework to govern the landlord-tenant relationship, promoting transparency, stability, and effective communication throughout the tenancy period.
It is essential for both parties to carefully review and negotiate the terms of the agreement before signing. Additionally, it is advised to seek legal advice to ensure compliance with all applicable laws and regulations within the UK.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
6
RATINGS
0
DISCUSSIONS
2
