Licence To Carry Out Works (Install Plant And Equipment Outside Boundary Of Property)
Publisher one
Genie AISource file
licence_to_carry_out_works_(install_plant_and_equipment_outside_boundary_of_property)_template.docxJurisdiction
England and WalesRelevant sectors
Type of legal document
🏚️ External works licenceBusiness activity
Install equipment outsideA external works licence covers any works that are carried out on the external parts of a property. This includes any works to the exterior of the property, such as the walls, windows, roof, gutters and drains.
The template could be used in various scenarios where the installation of such plant and equipment is necessary but requires access to an area outside the property's boundary. This could include cases such as telecommunications infrastructure installation, renewable energy projects, or utility-related equipment.
The document would outline the terms and conditions under which the licensee (the party seeking permission) is authorized to carry out the works on the property owner's land. It would cover aspects such as the scope of the proposed installation, the duration of the license, the specific location where the works will be conducted, and any limitations or restrictions imposed by the property owner.
The template would address legal aspects of the agreement, including liability, insurance requirements, compensation, indemnification, and potential penalties for non-compliance. It may also cover provisions related to the restoration of the property to its original condition once the works are completed or terminated.
As UK law governs the licensing arrangement, the template would ensure compliance with relevant regulations and statutes specific to the jurisdiction. However, it is important to note that the document would provide a starting point and may need customization by legal professionals to suit the specific circumstances and legal requirements of each situation.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Site Manager Contract
This Site Manager contract template is designed for a commercial site management organisation (or an individual site manager) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of site management and site-management-related services to be completed by the site manager on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the site management firm or individual site manager on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
Publisher
Genie AIJurisdiction
England and WalesStandard Application Notice to Court (Company Administration)
Company administration is a legal process that involves appointing an insolvency practitioner to take control of a financially troubled company's affairs. By submitting this Standard Application Notice to Court, the company seeks to gain court approval to enter administration, which is aimed at protecting the interests of the company's creditors and stakeholders while exploring options for possible recovery or restructuring.
The template typically includes crucial details such as the name and address of the company, a summary of the company's financial position, the reasons for seeking administration, and the proposed administrator's information. It may also outline any potential adverse effects that could arise from delaying or denying the administration request, emphasizing the urgency of court intervention.
This legal document plays a vital role in initiating the company administration process within the confines of UK law. It ensures that all necessary information is provided to the court, helping to establish a transparent and fair process for all parties involved.
