Contractor's Collateral Warranty (To Funder)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Create collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
This collateral warranty aims to safeguard the funder's interests by establishing a direct contractual relationship between the funder and the contractor. By doing so, the funder seeks additional assurances in terms of the contractor's performance, quality of work, and adherence to statutory regulations throughout the construction process.
The content of this legal document typically includes a detailed description of the project, its participants, and the main construction contract under which the project operates. It further outlines the specific obligations and warranties that the contractor provides to the funder, including the provision of performance guarantees, indemnities, and insurances.
Moreover, this template may specify the rights and remedies available to the funder in case the contractor fails to meet their obligations or breaches any contractual provision. These may include the right to terminate the collateral warranty, seek damages, or pursue legal actions to rectify any deviations from the agreed terms.
Under UK law, this Contractor's Collateral Warranty (To Funder) template ensures that the funder is adequately protected by establishing a legally binding framework to govern the contractual relationship with the contractor. It aims to minimize the financial risks associated with construction projects and provide the funder with the necessary remedies if issues arise during the execution of the project.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Site Manager Contract
This Site Manager contract template is designed for a commercial site management organisation (or an individual site manager) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of site management and site-management-related services to be completed by the site manager on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the site management firm or individual site manager on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
Publisher
Genie AIJurisdiction
England and WalesStandard Application Notice to Court (Company Administration)
Company administration is a legal process that involves appointing an insolvency practitioner to take control of a financially troubled company's affairs. By submitting this Standard Application Notice to Court, the company seeks to gain court approval to enter administration, which is aimed at protecting the interests of the company's creditors and stakeholders while exploring options for possible recovery or restructuring.
The template typically includes crucial details such as the name and address of the company, a summary of the company's financial position, the reasons for seeking administration, and the proposed administrator's information. It may also outline any potential adverse effects that could arise from delaying or denying the administration request, emphasizing the urgency of court intervention.
This legal document plays a vital role in initiating the company administration process within the confines of UK law. It ensures that all necessary information is provided to the court, helping to establish a transparent and fair process for all parties involved.
