All Templates
Provide collateral warranty
🏠 Collateral warranty
Collateral Warranty (Sub-Contractor to Funder)
Collateral Warranty (Sub-Contractor to Funder)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
🏠 Collateral warrantyBusiness activity
Provide collateral warrantyA collateral warranty is a separate agreement between the contractor and the employer that sets out additional terms and conditions relating to the works. The collateral warranty will often contain provisions relating to the quality of the works, the performance of the contractor, the liability of the contractor, and the indemnity of the employer. The collateral warranty will also contain a clause specifying that the agreement is collateral to the main contract and that it will remain in force even if the main contract is terminated.
A Collateral Warranty (Sub-Contractor to Funder) is a legal template under UK law that establishes a direct contractual agreement between a sub-contractor and a funder. This agreement serves as a form of assurance to the funder that the sub-contractor will fulfill its obligations as set forth in the original contract between the main contractor and the sub-contractor.
The purpose of this legal template is to provide financial protection to the funder by ensuring that the sub-contractor will perform its duties properly and avoid any potential breaches of contract. The collateral warranty serves as an additional layer of security for the funder, separate from the primary contract, in case the sub-contractor fails to meet its contractual obligations.
This legal document outlines the terms and conditions under which the sub-contractor agrees to provide the funder with certain warranties, indemnities, and guarantees. It may cover aspects such as the quality of work, adherence to health and safety standards, compliance with relevant regulations, liability for defects, and completion within specified timelines.
The collateral warranty typically details the rights and obligations of both parties, including the circumstances in which the funder may make a claim against the sub-contractor for any breach of contract. It may also include provisions for dispute resolution mechanisms, such as arbitration or mediation, in case disagreements arise between the parties.
This legal template is commonly used in construction and infrastructure projects where subcontractors are involved and financiers seek additional protection for their investment. By entering into this collateral warranty, the sub-contractor accepts a direct contractual relationship with the funder and assumes additional responsibilities to ensure the successful completion of the project.
It is essential for both parties involved in the collateral warranty agreement to thoroughly review and understand the terms before signing. Seeking legal advice is advisable to ensure the document reflects the specific requirements of the project and adequately protects the interests of both the funder and sub-contractor.
The purpose of this legal template is to provide financial protection to the funder by ensuring that the sub-contractor will perform its duties properly and avoid any potential breaches of contract. The collateral warranty serves as an additional layer of security for the funder, separate from the primary contract, in case the sub-contractor fails to meet its contractual obligations.
This legal document outlines the terms and conditions under which the sub-contractor agrees to provide the funder with certain warranties, indemnities, and guarantees. It may cover aspects such as the quality of work, adherence to health and safety standards, compliance with relevant regulations, liability for defects, and completion within specified timelines.
The collateral warranty typically details the rights and obligations of both parties, including the circumstances in which the funder may make a claim against the sub-contractor for any breach of contract. It may also include provisions for dispute resolution mechanisms, such as arbitration or mediation, in case disagreements arise between the parties.
This legal template is commonly used in construction and infrastructure projects where subcontractors are involved and financiers seek additional protection for their investment. By entering into this collateral warranty, the sub-contractor accepts a direct contractual relationship with the funder and assumes additional responsibilities to ensure the successful completion of the project.
It is essential for both parties involved in the collateral warranty agreement to thoroughly review and understand the terms before signing. Seeking legal advice is advisable to ensure the document reflects the specific requirements of the project and adequately protects the interests of both the funder and sub-contractor.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Sub-Underlet License (Whole or Part Of Property)
The Sub-Underlet License (Whole or Part Of Property) legal template under UK law is a document that outlines the terms and conditions for the sub-underletting of all or a portion of a property. In the United Kingdom, sub-underletting refers to the act of a tenant (the sub-lessee) subletting the property they are renting from the landlord (the head lessor) to another party (the sub-underlessee).
This legal template provides a framework for documenting the agreement between the tenant and the sub-underlessee, ensuring that both parties are aware of their rights, responsibilities, and obligations in the sub-underletting arrangement. It covers various aspects such as the duration of the sub-underlet, rent payments, maintenance responsibilities, access to common areas (if applicable), and any restrictions or conditions imposed by the head lessor.
By using this legally binding template, both the sub-lessee and the sub-underlessee can clarify the terms of their agreement, protecting their respective interests and minimizing potential disputes. It ensures compliance with UK law and provides a clear legal framework for the sub-underletting relationship.
This legal template provides a framework for documenting the agreement between the tenant and the sub-underlessee, ensuring that both parties are aware of their rights, responsibilities, and obligations in the sub-underletting arrangement. It covers various aspects such as the duration of the sub-underlet, rent payments, maintenance responsibilities, access to common areas (if applicable), and any restrictions or conditions imposed by the head lessor.
By using this legally binding template, both the sub-lessee and the sub-underlessee can clarify the terms of their agreement, protecting their respective interests and minimizing potential disputes. It ensures compliance with UK law and provides a clear legal framework for the sub-underletting relationship.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
3
RATINGS
1
DISCUSSIONS
0
Sub-Contract for Minor Works (With Sub-Contractor's Design)
This legal template is a contract specifically designed for sub-contractors who are responsible for providing minor works with their own design under the jurisdiction of UK law. It outlines the terms and conditions that govern the interaction between the main contractor and the sub-contractor, ensuring clarity and providing legal protection for both parties involved in the arrangement.
This sub-contract agreement covers various aspects such as the scope of work to be performed, the agreed-upon timeline for completion, payment terms, deliverables, and any specific design requirements. It also includes provisions related to quality standards, health and safety regulations, insurance and liabilities, intellectual property rights, and dispute resolution mechanisms.
By utilizing this template, the main contractor and sub-contractor can establish a legally binding agreement that defines the roles, responsibilities, and obligations of each party. This document not only ensures that both parties are on the same page regarding expectations but also helps protect their respective interests and minimize any potential disputes that may arise during the course of the project.
It is important to note that although this template provides a comprehensive framework, it may still need to be customized to meet the specific needs and requirements of the main contractor and sub-contractor. Consequently, professional legal advice may be necessary to ensure the final agreement aligns with UK law and considers the unique circumstances of the parties involved in the sub-contract for minor works with the sub-contractor's design.
This sub-contract agreement covers various aspects such as the scope of work to be performed, the agreed-upon timeline for completion, payment terms, deliverables, and any specific design requirements. It also includes provisions related to quality standards, health and safety regulations, insurance and liabilities, intellectual property rights, and dispute resolution mechanisms.
By utilizing this template, the main contractor and sub-contractor can establish a legally binding agreement that defines the roles, responsibilities, and obligations of each party. This document not only ensures that both parties are on the same page regarding expectations but also helps protect their respective interests and minimize any potential disputes that may arise during the course of the project.
It is important to note that although this template provides a comprehensive framework, it may still need to be customized to meet the specific needs and requirements of the main contractor and sub-contractor. Consequently, professional legal advice may be necessary to ensure the final agreement aligns with UK law and considers the unique circumstances of the parties involved in the sub-contract for minor works with the sub-contractor's design.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
12
RATINGS
2
DISCUSSIONS
1
Sub-Contractor Collateral Warranty (Pro-Employer)
The legal template of the Sub-Contractor Collateral Warranty (Pro-Employer) under UK law is a comprehensive and standardized document that sets out the rights and obligations of a sub-contractor towards a third party employer in a construction project. This particular template is designed to heavily favor the employer's interests and offers additional protection to the employer in case of breach or negligence by the sub-contractor.
The document covers various aspects related to the sub-contractor's responsibilities, performance expectations, and potential liabilities in relation to the employer and any third parties directly affected by the construction project. It outlines the scope of work for the sub-contractor, specifying the tasks, timelines, quality standards, and any applicable regulations or industry standards that must be adhered to.
Additionally, the template ensures that the sub-contractor provides the necessary warranties, guarantees, and indemnities to the employer. These provisions serve to safeguard the employer against any financial losses, damages, or delays caused by the sub-contractor's actions or omissions. The template may also include details about insurance requirements, in order to ensure that both parties are adequately covered throughout the duration of the project.
Furthermore, this template may address dispute resolution mechanisms, such as arbitration or mediation, to resolve any conflicts that may arise between the sub-contractor and the employer. It may also specify the governing law and jurisdiction under which any legal disputes will be resolved, which in this case is UK law.
Overall, the Sub-Contractor Collateral Warranty (Pro-Employer) template emphasizes the employer's interests by establishing a clear framework of obligations and liabilities for the sub-contractor. By utilizing this legal document, both parties can have a comprehensive understanding of their respective roles and responsibilities, providing a foundation for a smoother and more transparent working relationship.
The document covers various aspects related to the sub-contractor's responsibilities, performance expectations, and potential liabilities in relation to the employer and any third parties directly affected by the construction project. It outlines the scope of work for the sub-contractor, specifying the tasks, timelines, quality standards, and any applicable regulations or industry standards that must be adhered to.
Additionally, the template ensures that the sub-contractor provides the necessary warranties, guarantees, and indemnities to the employer. These provisions serve to safeguard the employer against any financial losses, damages, or delays caused by the sub-contractor's actions or omissions. The template may also include details about insurance requirements, in order to ensure that both parties are adequately covered throughout the duration of the project.
Furthermore, this template may address dispute resolution mechanisms, such as arbitration or mediation, to resolve any conflicts that may arise between the sub-contractor and the employer. It may also specify the governing law and jurisdiction under which any legal disputes will be resolved, which in this case is UK law.
Overall, the Sub-Contractor Collateral Warranty (Pro-Employer) template emphasizes the employer's interests by establishing a clear framework of obligations and liabilities for the sub-contractor. By utilizing this legal document, both parties can have a comprehensive understanding of their respective roles and responsibilities, providing a foundation for a smoother and more transparent working relationship.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
2
DISCUSSIONS
0
