All Countries
Commercial
Renovation Agreement Between Owner And Contractor

Renovation Agreement Between Owner And Contractor Template for New Zealand

Create a bespoke document in minutes,  or upload and review your own.

4.6 / 5
4.8 / 5

Let's create your Renovation Agreement Between Owner And Contractor

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Renovation Agreement Between Owner And Contractor

"I need a Renovation Agreement Between Owner And Contractor for a high-end residential kitchen renovation project valued at NZD 150,000, with specific provisions for imported Italian fixtures and a completion deadline of March 2025."

Celebrated by
Collaborations with
Investors
Document background
The Renovation Agreement Between Owner And Contractor is a crucial legal document used in New Zealand when undertaking property renovations, whether residential or commercial. This agreement is designed to comply with New Zealand's construction and contract law framework, including the Building Act 2004 and Construction Contracts Act 2002. It should be used whenever a property owner engages a contractor for significant renovation works, protecting both parties by clearly defining the scope of work, payment terms, timelines, and responsibilities. The agreement includes essential provisions for building consent requirements, health and safety compliance, warranty terms, and dispute resolution procedures specific to the New Zealand construction industry. It serves as a foundational document that helps prevent misunderstandings and provides a clear framework for project execution and completion.
Suggested Sections

1. Parties: Identification of the property owner and the contractor, including full legal names, addresses, and any relevant registration numbers

2. Background: Brief context of the renovation project and purpose of the agreement

3. Definitions: Definitions of key terms used throughout the agreement

4. Scope of Work: Detailed description of the renovation work to be performed, including specific inclusions and exclusions

5. Contract Price and Payment Terms: Total contract price, payment schedule, deposit requirements, and progress payment details

6. Timeline and Completion: Project start date, completion date, and any milestone dates

7. Contractor's Obligations: Key responsibilities including workmanship, materials, permits, supervision, and site management

8. Owner's Obligations: Access requirements, decision-making timeframes, and other owner responsibilities

9. Materials and Workmanship: Quality standards, material specifications, and workmanship warranties

10. Variations: Process for requesting, approving, and charging for variations to the scope of work

11. Health and Safety: Safety requirements, site management, and respective responsibilities under health and safety legislation

12. Insurance and Liability: Required insurance coverage and allocation of risk between parties

13. Warranties: Workmanship guarantees and manufacturer warranties for materials

14. Default and Termination: Events of default, remedies, and termination processes

15. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures

16. General Provisions: Standard contract clauses including notices, assignment, and governing law

Optional Sections

1. Consent Requirements: Include when the renovation requires specific building or resource consents

2. Subcontractors: Include when subcontractors will be used, specifying management and approval processes

3. Weather Conditions: Include for external work that may be affected by weather

4. Heritage Requirements: Include for properties with heritage status or special architectural features

5. Occupancy During Works: Include when the property will remain occupied during renovation

6. Temporary Services: Include when temporary utilities or facilities are required

7. Site Access and Storage: Include for projects requiring significant material storage or complex access arrangements

8. Protection of Existing Structure: Include for renovations affecting significant portions of existing building

9. Noise and Disruption Management: Include for projects in sensitive areas or with specific noise restrictions

10. Sustainable Building Practices: Include when specific environmental or sustainability requirements apply

Suggested Schedules

1. Schedule 1: Scope of Works: Detailed specifications, plans, and drawings of the renovation work

2. Schedule 2: Price Breakdown: Itemized costs for labor, materials, and other components

3. Schedule 3: Project Timeline: Detailed project schedule including milestones and critical path activities

4. Schedule 4: Materials Schedule: Specifications of all materials to be used, including brands and models

5. Schedule 5: Warranties and Guarantees: Copies of specific warranties and guarantees for works and materials

6. Appendix A: Building Consent Documents: Copies of building consent and related correspondence

7. Appendix B: Plans and Drawings: Architectural and engineering drawings

8. Appendix C: Health and Safety Plan: Site-specific safety plan and procedures

9. Appendix D: Insurance Certificates: Copies of required insurance policies

10. Appendix E: Product Specifications: Technical specifications for major items and fixtures

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Linkedin in social icon imageX social icon image
alex.den.21@genieai.co
Relevant legal definitions
Agreement
Approved Variations
Building Consent
Building Work
Certificate of Practical Completion
Completion Date
Contract Price
Contract Documents
Contractor
Day
Defects Liability Period
Deposit
Existing Structure
Force Majeure Event
GST
Health and Safety Plan
Loss
Materials
Owner
Payment Claim
Payment Schedule
Permits
Plans and Specifications
Practical Completion
Progress Payment
Project
Property
Renovation Works
Retention Sum
Schedule of Works
Site
Specifications
Subcontractor
Substantial Completion
Variation
Working Day
Works
Workmanship
Relevant Industries

Construction

Real Estate

Property Development

Architecture

Interior Design

Building and Construction Services

Home Improvement

Commercial Property

Residential Property

Property Management

Relevant Teams

Legal

Construction

Property Management

Project Management

Compliance

Operations

Contract Administration

Quality Assurance

Risk Management

Commercial

Relevant Roles

Construction Manager

Project Manager

Property Developer

Building Contractor

Architect

Quantity Surveyor

Contract Administrator

Property Owner

Legal Counsel

Construction Site Manager

Renovation Specialist

Building Inspector

Compliance Officer

Property Manager

Industries
Building Act 2004: Primary legislation governing building work in New Zealand, including requirements for building consents, compliance with building code, and ensuring construction meets required standards
Construction Contracts Act 2002: Regulates payment processes in construction contracts, provides dispute resolution procedures, and sets requirements for construction contracts
Health and Safety at Work Act 2015: Ensures workplace safety requirements are met during renovation work, including responsibilities of contractors and property owners
Fair Trading Act 1986: Protects against misleading and deceptive conduct in trade, ensuring honest representation of services and materials
Consumer Guarantees Act 1993: Provides statutory guarantees for services, including that work will be carried out with reasonable care and skill
Contract and Commercial Law Act 2017: Governs general contract law principles applicable to renovation agreements, including formation, terms, and remedies
Building Regulations 1992 (Building Code): Sets performance standards for building work, including structural stability, durability, and safety requirements
Resource Management Act 1991: May be relevant if renovation work requires resource consent or affects environmental matters
Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Project Management Contract In (Construction)

New Zealand-governed construction project management agreement defining services, responsibilities, and compliance requirements for managing construction projects.

find out more

Project Management Agreement (Construction)

A New Zealand-governed agreement defining the engagement terms and responsibilities of a project manager for construction project delivery.

find out more

Novation Agreement (Construction)

A New Zealand construction contract novation agreement that transfers rights and obligations from an existing contractor to a new contractor, ensuring project continuity and compliance with local construction laws.

find out more

Land Purchase Proposal

A formal proposal document for initiating land or property purchase in New Zealand, outlining key terms and conditions under NZ property law.

find out more

Independent Contractor Agreement For (Construction)

New Zealand-compliant Independent Contractor Agreement for construction projects, addressing key legal and operational requirements under NZ law.

find out more

Framework Agreement (Construction)

A New Zealand-governed agreement establishing terms for multiple construction projects between a client and contractor over an extended period.

find out more

Design Agreement For (Construction)

A New Zealand-governed agreement establishing terms and conditions for providing professional design services in construction projects, including scope, obligations, and deliverables.

find out more

Construction Consulting Agreement

A New Zealand-compliant agreement governing construction consulting services, including scope, obligations, and terms under local construction laws.

find out more

Contract For Project Management Services

New Zealand-governed agreement for professional project management services, defining scope, responsibilities, and commercial terms between client and project manager.

find out more

Commercial In Confidence Agreement

A New Zealand-governed agreement establishing confidentiality obligations between parties for protecting sensitive business information.

find out more

Film Shopping Agreement

A New Zealand-governed agreement authorizing a representative to shop and negotiate deals for a film project, defining scope, rights, and compensation terms.

find out more

Design Build Finance Contract

A New Zealand-governed contract combining design, construction, and financing obligations under a single integrated agreement, structured according to NZ construction and financial regulations.

find out more

Design And Build Agreement

A New Zealand-governed agreement combining design and construction obligations into a single contract for project delivery.

find out more

Agreement For Demolition Of Building

A New Zealand-governed agreement setting out terms and conditions for building demolition works, including safety requirements and regulatory compliance.

find out more

Project Labour Agreement

A New Zealand-compliant agreement establishing uniform labor terms and conditions for all workers on a specific construction project.

find out more

Project Financing Agreement

A New Zealand law-governed agreement establishing terms for project-specific financing, including facility details, security arrangements, and compliance requirements.

find out more

Non Disclosure Agreement For Design Work

New Zealand-compliant NDA template for protecting confidential information in design work engagements.

find out more

Design Build Lump Sum Contract

New Zealand Design Build Lump Sum Contract template for fixed-price construction projects combining design and build obligations under NZ law.

find out more

Residential Architect Contract

A New Zealand-compliant contract establishing terms between an architect and residential client for architectural services.

find out more

Project Based Agreement

A New Zealand-governed agreement that defines terms, conditions, and deliverables for a specific project between contracting parties.

find out more

Freelance Project Contract

A New Zealand-governed contract defining terms and conditions for project-based freelance work, including scope, deliverables, and payment terms.

find out more

Design Build Contract

New Zealand-compliant Design Build Contract template combining design and construction responsibilities under single contractor engagement.

find out more

Project Support Agreement

A New Zealand-governed agreement establishing terms for project support services, including scope, payment, and service obligations.

find out more

Project Alliance Agreement

A collaborative agreement under New Zealand law establishing a legal framework for multiple parties to deliver complex infrastructure projects under shared risk-reward arrangements.

find out more

Consortium Agreement Construction Project

A New Zealand-governed agreement establishing a consortium between multiple parties for executing a construction project, defining their rights, responsibilities, and operational framework.

find out more

Renovation Agreement Between Owner And Contractor

A New Zealand-compliant legal agreement between property owner and contractor setting terms for renovation works, including scope, payments, and responsibilities.

find out more

Project Profit Sharing Agreement

A New Zealand law-governed agreement establishing profit-sharing arrangements between parties collaborating on a specific project, including calculation methods, distribution mechanisms, and governance framework.

find out more

Project Delivery Agreement

A New Zealand-governed agreement defining terms and conditions for project delivery between a principal and contractor, including deliverables, timelines, and responsibilities.

find out more

Pilot Project Agreement

A New Zealand-governed agreement establishing terms and conditions for implementing and evaluating a pilot project between parties.

find out more

Project Service Agreement

A New Zealand-governed agreement establishing terms for project-based service delivery between a service provider and client.

find out more

Electrical Subcontractor Agreement

New Zealand-governed agreement between main contractor and electrical subcontractor for electrical works, incorporating local electrical safety and construction regulations.

find out more

Commercial Supply Agreement

A New Zealand-governed agreement establishing terms and conditions for ongoing supply of goods or services between businesses.

find out more

Road Construction Agreement

A New Zealand-governed agreement establishing terms and conditions for road construction projects, including specifications, responsibilities, and compliance requirements.

find out more

Project Funding Agreement

A New Zealand-governed agreement establishing terms and conditions for project funding, including payment terms, deliverables, and compliance requirements.

find out more

Roofing Subcontractor Agreement

A New Zealand-compliant agreement between a main contractor and roofing subcontractor for specialized roofing works, including terms, conditions, and regulatory requirements.

find out more

Project Cooperation Agreement

A New Zealand-governed agreement establishing terms for multi-party project collaboration, including scope, responsibilities, and delivery requirements.

find out more

Project Agreement Contract

A New Zealand-governed agreement that establishes terms, conditions, and responsibilities for project execution between contracting parties.

find out more

Construction Settlement Agreement

A New Zealand-governed agreement for settling construction-related disputes and claims, providing a framework for resolution and completion of construction projects.

find out more

Consortium Agreement For Tender

A New Zealand-governed agreement establishing a consortium structure between multiple parties for joint tender submission, defining roles, responsibilities, and collaboration terms.

find out more

Renovation Agreement

A New Zealand-compliant agreement setting out terms and conditions for property renovation works, including scope, payments, and responsibilities of contractors and property owners.

find out more

Demolition Agreement

A New Zealand-governed agreement setting out terms and conditions for building demolition works, including safety, environmental, and regulatory compliance requirements.

find out more

Remodeling Contractor Agreement

A New Zealand-compliant contract governing the terms and conditions between a contractor and property owner for remodeling works.

find out more

Project Development Agreement

A New Zealand-governed agreement establishing terms and conditions for property development projects, including scope, obligations, and delivery requirements.

find out more

General Construction Agreement

A New Zealand-compliant construction agreement establishing terms and conditions between principal and contractor for building works.

find out more

Proof Of Concept Agreement

A New Zealand law-governed agreement for conducting and evaluating proof of concept trials of new technologies or solutions.

find out more

Contract Agreement For Construction Work

A New Zealand-compliant construction contract agreement establishing terms, conditions, and obligations between principal/owner and contractor for construction works.

find out more

Construction Letter Of Intent

A New Zealand-compliant pre-contractual document authorizing commencement of construction works while final contract terms are being negotiated.

find out more

Construction Management Contract

A New Zealand-governed agreement between a principal and construction manager defining the terms and conditions for managing construction project delivery.

find out more

Download our whitepaper on the future of AI in Legal

By providing your email address you are consenting to our Privacy Notice.
Thank you for downloading our whitepaper. This should arrive in your inbox shortly. In the meantime, why not jump straight to a section that interests you here: https://www.genieai.co/our-research
Oops! Something went wrong while submitting the form.

Genie’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; Genie’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

Our bank-grade security infrastructure undergoes regular external audits

We are ISO27001 certified, so your data is secure

Organizational security

You retain IP ownership of your documents

You have full control over your data and who gets to see it

Innovation in privacy:

Genie partnered with the Computational Privacy Department at Imperial College London

Together, we ran a £1 million research project on privacy and anonymity in legal contracts

Want to know more?

Visit our Trust Centre for more details and real-time security updates.

Read our Privacy Policy.