Owner Builder Subcontractor Agreement Template for England and Wales

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Owner Builder Subcontractor Agreement

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Owner Builder Subcontractor Agreement

"I need an Owner Builder Subcontractor Agreement for a residential renovation project in Manchester, where I'll be hiring a specialist contractor for electrical works valued at £50,000, with works scheduled to commence in March 2025."

Document background

The Owner Builder Subcontractor Agreement is essential for construction projects in England and Wales where owner-builders need to engage specialist contractors. This document is particularly crucial when self-managing construction projects, as it provides the necessary legal framework to protect all parties' interests. The agreement encompasses critical elements such as scope definition, payment mechanisms, timeline commitments, and quality standards, while ensuring compliance with relevant construction legislation and regulations. It's designed to prevent disputes by clearly outlining responsibilities and expectations, making it an indispensable tool for effective project management.

Suggested Sections

1. Parties: Identification and details of the Owner/Principal Contractor and Subcontractor

2. Background: Context of the agreement and brief project overview

3. Definitions: Key terms used throughout the agreement

4. Scope of Works: Detailed description of works to be performed by the subcontractor

5. Contract Price and Payment Terms: Payment amounts, schedule, and mechanisms including compliance with Construction Act 1996

6. Project Timeline: Commencement date, completion date, and key milestones

7. Health and Safety Obligations: Safety requirements and CDM 2015 compliance

8. Insurance Requirements: Mandatory insurance coverage and limits

9. Warranties and Quality Standards: Quality guarantees and workmanship standards

10. Termination: Conditions for contract termination

Optional Sections

1. Materials and Equipment: Responsibilities for supply and storage of materials - use when materials supply is split between parties

2. Variations: Process for handling changes to scope - include for complex projects likely to require changes

3. Liquidated Damages: Predetermined damages for delay or breach - include when specific completion dates are critical

4. Performance Bond: Requirements for performance security - include for high-value contracts

5. Intellectual Property: Rights to designs and innovations - include when custom designs or methods are involved

Suggested Schedules

1. Schedule 1 - Scope of Works: Detailed specifications and drawings

2. Schedule 2 - Payment Schedule: Detailed breakdown of payments and milestones

3. Schedule 3 - Programme of Works: Detailed timeline and project schedule

4. Schedule 4 - Site Rules: Specific site regulations and procedures

5. Appendix A - Insurance Certificates: Copies of required insurance policies

6. Appendix B - Health and Safety Plan: Detailed H&S procedures and risk assessments

7. Appendix C - Quality Control Plan: Quality assurance procedures and standards

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Relevant Teams

Relevant Roles

Industries

Construction Act 1996: Housing Grants, Construction and Regeneration Act - Primary legislation governing construction contracts, payment mechanisms, and dispute resolution in the UK construction industry

CDM Regulations 2015: Construction (Design and Management) Regulations that specify duties and responsibilities for health, safety, and welfare in construction projects

Building Act 1984: Fundamental legislation controlling building work and setting standards for construction, including Building Regulations 2010

Late Payment of Commercial Debts Act 1998: Legislation governing payment terms and interest on late payments in commercial transactions

Scheme for Construction Contracts: Regulations providing default payment and adjudication provisions for construction contracts in England and Wales

Health and Safety at Work Act 1974: Primary legislation for workplace health and safety in the UK, setting out general duties for employers and workers

Work at Height Regulations 2005: Specific regulations governing safety requirements for working at height in construction and other industries

COSHH Regulations 2002: Control of Substances Hazardous to Health Regulations governing the use and handling of hazardous materials

Working Time Regulations 1998: Legislation governing working hours, rest periods, and annual leave entitlements

Employment Rights Act 1996: Core employment legislation defining basic employment rights and responsibilities

Modern Slavery Act 2015: Legislation aimed at preventing modern slavery and human trafficking in supply chains and businesses

Employers' Liability Act 1969: Requires employers to maintain insurance against liability for injury or disease to their employees

Environmental Protection Act 1990: Framework for environmental protection, waste management, and pollution control in construction activities

Unfair Contract Terms Act 1977: Regulates contracts by restricting how far civil liability for breach of contract can be avoided

UK GDPR and DPA 2018: Data protection legislation governing the processing and handling of personal data

Construction Industry Scheme: Tax regulations specific to the construction industry, governing payments to subcontractors

Party Wall Act 1996: Legislation governing works affecting party walls, boundaries, and excavations near neighboring buildings

Common Law Contract Principles: Fundamental legal principles governing contract formation, terms, breach, and remedies in English law

How Genie AI reduced drafting time by 75% for a legal firm

Let's create your Owner Builder Subcontractor Agreement

Authors

Alex Denne

Find the exact document you need

Standard Building Contract

New Build Purchase Agreement

Construction Management At Risk Agreement

Construction Completion Agreement

Contract Between Builder And Subcontractor

Contractor Contingency Agreement

Contractor And Owner Agreement

Builder Purchase Agreement

Contractor Warranty Agreement

Building Material Contract Agreement

Pre Construction Purchase Agreement

Agreement Between Builder And Contractor

Construction Finders Fee Agreement

General Contractor Subcontractor Agreement

Owner Subcontractor Agreement

Building Construction Contract Agreement

Owner Builder Subcontractor Agreement

Construction Retainer Agreement

Agreement Between Land Owner And Builder

Sale And Construction Agreement

Management Building Contract

Commercial Construction Agreement

Owner Builder Agreement

Builder Development Agreement

Construction Payment Contract

New Construction Home Contract

Construction Equipment Lease Agreement

Construction Equipment Rental Agreement

Download our whitepaper on the future of AI in Legal

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security

Innovation in privacy:

Want to know more?

Draft quality legal agreements or review documents in 3 minutes

Templates

Commercial

Employment

IP

Administration

Finance

R&D

Industries

Legal Services

Manufacturing

Construction

Solutions

Use Cases

Company Types

Comparisons

Business Categories

Teams

Information