All Templates
Send default notice
📄 Section 278 agreement
Section 278 Agreement: Notice Of Default (Council To Developer)
Section 278 Agreement: Notice Of Default (Council To Developer)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
📄 Section 278 agreementBusiness activity
Send default noticeA Section 278 agreement is a legal agreement between a developer and a local authority that sets out the terms and conditions under which the developer can carry out work on a public highway. The agreement will cover things like the timing of the work, the type of work that can be carried out, and any restrictions that the local authority imposes on the work.
The Section 278 Agreement: Notice Of Default (Council To Developer) under UK law is a legal template that outlines the procedure and requirements for notifying a developer of default under a Section 278 Agreement. Section 278 Agreements are typically entered into between a local authority (council) and a developer for the purpose of facilitating necessary highway works that are related to a development project.
This template provides the necessary framework for the local authority to formally notify the developer when they are in breach of their obligations or have failed to adhere to the terms outlined in the Section 278 Agreement. The notice of default serves as a formal communication, triggering certain legal consequences to rectify the default and ensuring the progress of the development project.
The agreement may specify different types of defaults, such as failure to complete works within the agreed timeframe, failure to provide required documentation, financial defaults, or non-compliance with relevant regulations. The notice of default describes the specific nature of the breach, the corresponding clause or provision of the Section 278 Agreement that has been violated, and the necessary steps to rectify the default.
The template also highlights the potential consequences of the default, which could include financial penalties, suspension of the development project, or even termination of the Section 278 Agreement. It may also outline the dispute resolution process in case the developer wishes to contest the notice of default or negotiate alternative solutions.
This legal template is designed to provide clarity, structure, and consistency in addressing defaults under a Section 278 Agreement, ensuring that both parties are aware of their rights, obligations, and the necessary steps to remedy any breach. It is intended to serve as a guide for local authorities in maintaining accountability and enforcing compliance with the terms of the agreement between the council and the developer.
This template provides the necessary framework for the local authority to formally notify the developer when they are in breach of their obligations or have failed to adhere to the terms outlined in the Section 278 Agreement. The notice of default serves as a formal communication, triggering certain legal consequences to rectify the default and ensuring the progress of the development project.
The agreement may specify different types of defaults, such as failure to complete works within the agreed timeframe, failure to provide required documentation, financial defaults, or non-compliance with relevant regulations. The notice of default describes the specific nature of the breach, the corresponding clause or provision of the Section 278 Agreement that has been violated, and the necessary steps to rectify the default.
The template also highlights the potential consequences of the default, which could include financial penalties, suspension of the development project, or even termination of the Section 278 Agreement. It may also outline the dispute resolution process in case the developer wishes to contest the notice of default or negotiate alternative solutions.
This legal template is designed to provide clarity, structure, and consistency in addressing defaults under a Section 278 Agreement, ensuring that both parties are aware of their rights, obligations, and the necessary steps to remedy any breach. It is intended to serve as a guide for local authorities in maintaining accountability and enforcing compliance with the terms of the agreement between the council and the developer.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Wording For Et1 (Sexual Harassment And Constructive Dismissal)
The legal template titled "Wording For ET1 (Sexual Harassment And Constructive Dismissal) under UK law" is designed to assist individuals in drafting their official claim document, known as ET1, when they have experienced both sexual harassment and constructive dismissal in the workplace under the jurisdiction of UK law.
The template primarily focuses on two distinct legal issues. Firstly, it addresses claims of sexual harassment, which often involves any unwelcome behavior, comments, or advances of a sexual nature that create an intimidating, hostile, or offensive environment at work. The template provides guidance on presenting a clear and concise account of the instances of sexual harassment faced, including details of dates, locations, individuals involved, and the impact it had on the claimant's well-being or work performance.
Secondly, the template addresses claims of constructive dismissal, which occurs when an employer's conduct or breach of contract fundamentally undermines the working relationship, forcing the employee to resign. It provides guidance on presenting the circumstances leading to a constructive dismissal claim, such as any significant changes to job responsibilities, bullying tactics, discriminatory treatment, or inadequate response from the employer to address the claimant's concerns.
Additionally, the template may offer corresponding legal references, examples, or specific legal language that can be tailored to the individual's unique circumstances. It aims to ensure that the ET1 document accurately reflects the claimant's experiences, providing a strong foundation for their case in the Employment Tribunal.
However, it is essential to note that the template is not a substitute for legal advice or professional representation. It should be used as a starting point, allowing individuals to draft their claim document with the necessary legal structure, providing a solid basis for their particular case of both sexual harassment and constructive dismissal under UK law.
The template primarily focuses on two distinct legal issues. Firstly, it addresses claims of sexual harassment, which often involves any unwelcome behavior, comments, or advances of a sexual nature that create an intimidating, hostile, or offensive environment at work. The template provides guidance on presenting a clear and concise account of the instances of sexual harassment faced, including details of dates, locations, individuals involved, and the impact it had on the claimant's well-being or work performance.
Secondly, the template addresses claims of constructive dismissal, which occurs when an employer's conduct or breach of contract fundamentally undermines the working relationship, forcing the employee to resign. It provides guidance on presenting the circumstances leading to a constructive dismissal claim, such as any significant changes to job responsibilities, bullying tactics, discriminatory treatment, or inadequate response from the employer to address the claimant's concerns.
Additionally, the template may offer corresponding legal references, examples, or specific legal language that can be tailored to the individual's unique circumstances. It aims to ensure that the ET1 document accurately reflects the claimant's experiences, providing a strong foundation for their case in the Employment Tribunal.
However, it is essential to note that the template is not a substitute for legal advice or professional representation. It should be used as a starting point, allowing individuals to draft their claim document with the necessary legal structure, providing a solid basis for their particular case of both sexual harassment and constructive dismissal under UK law.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
8
RATINGS
2
DISCUSSIONS
0
Consultant & Contractor NDA (Construction)
This legal template primarily focuses on establishing a Non-Disclosure Agreement (NDA) between a consultant and a contractor in the construction industry, specifically under the jurisdiction of UK law. An NDA is a legally binding contract that outlines the terms and conditions governing the confidentiality of sensitive information shared between the parties involved.
The template aims to protect the proprietary and confidential information exchanged during their professional relationship, ensuring that it remains confidential and restricted from disclosure to any unauthorized individuals or entities. Both the consultant and contractor are expected to maintain strict confidentiality during and after their engagement with each other.
The NDA template may cover various aspects such as the definition and scope of confidential information, the obligations and responsibilities of the parties in protecting such information, the duration of the agreement, and the consequences of any breach of the NDA. It may also address circumstances under which disclosure might be legally required, providing exceptions and appropriate procedures for such scenarios.
By utilizing this comprehensive legal template, the consultant and contractor can establish a clear understanding of their confidentiality obligations, ensuring that their respective businesses' sensitive information and trade secrets are safeguarded against unauthorized use or disclosure.
The template aims to protect the proprietary and confidential information exchanged during their professional relationship, ensuring that it remains confidential and restricted from disclosure to any unauthorized individuals or entities. Both the consultant and contractor are expected to maintain strict confidentiality during and after their engagement with each other.
The NDA template may cover various aspects such as the definition and scope of confidential information, the obligations and responsibilities of the parties in protecting such information, the duration of the agreement, and the consequences of any breach of the NDA. It may also address circumstances under which disclosure might be legally required, providing exceptions and appropriate procedures for such scenarios.
By utilizing this comprehensive legal template, the consultant and contractor can establish a clear understanding of their confidentiality obligations, ensuring that their respective businesses' sensitive information and trade secrets are safeguarded against unauthorized use or disclosure.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
5
RATINGS
2
DISCUSSIONS
1
Simple Livery Agreement
A Simple Livery Agreement under UK law is a legal template that outlines the terms and conditions between a horse owner (the "Owner") and a livery yard owner (the "Livery Yard") regarding the boarding and care of the Owner's horse. This agreement serves as a legally binding contract that ensures both parties are clear on their responsibilities and obligations.
The agreement typically covers essential details such as the horse's identification information, the boarding period, and the boarding fees. It includes provisions regarding the horse's accommodation, feed, exercise, and care requirements, as well as the Livery Yard's responsibilities in maintaining a safe and suitable environment for the horse.
Other important aspects that may be addressed in this template may include the Livery Yard's liability for any injury or damage caused to the horse, the requirement for appropriate horse insurance, and provisions for termination or renewal of the agreement. It may also specify any additional services offered by the Livery Yard, such as grooming or training, and the associated costs.
By utilizing this legal template, both the Owner and the Livery Yard can have a clear understanding of their respective rights and obligations, thereby helping to establish a transparent and harmonious working relationship.
The agreement typically covers essential details such as the horse's identification information, the boarding period, and the boarding fees. It includes provisions regarding the horse's accommodation, feed, exercise, and care requirements, as well as the Livery Yard's responsibilities in maintaining a safe and suitable environment for the horse.
Other important aspects that may be addressed in this template may include the Livery Yard's liability for any injury or damage caused to the horse, the requirement for appropriate horse insurance, and provisions for termination or renewal of the agreement. It may also specify any additional services offered by the Livery Yard, such as grooming or training, and the associated costs.
By utilizing this legal template, both the Owner and the Livery Yard can have a clear understanding of their respective rights and obligations, thereby helping to establish a transparent and harmonious working relationship.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
12
RATINGS
5
DISCUSSIONS
1
