All Templates
Send default notice
📄 Section 278 agreement
Section 278 Agreement: Notice Of Default (Council To Developer)
Section 278 Agreement: Notice Of Default (Council To Developer)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
📄 Section 278 agreementBusiness activity
Send default noticeA Section 278 agreement is a legal agreement between a developer and a local authority that sets out the terms and conditions under which the developer can carry out work on a public highway. The agreement will cover things like the timing of the work, the type of work that can be carried out, and any restrictions that the local authority imposes on the work.
The Section 278 Agreement: Notice Of Default (Council To Developer) under UK law is a legal template that outlines the procedure and requirements for notifying a developer of default under a Section 278 Agreement. Section 278 Agreements are typically entered into between a local authority (council) and a developer for the purpose of facilitating necessary highway works that are related to a development project.
This template provides the necessary framework for the local authority to formally notify the developer when they are in breach of their obligations or have failed to adhere to the terms outlined in the Section 278 Agreement. The notice of default serves as a formal communication, triggering certain legal consequences to rectify the default and ensuring the progress of the development project.
The agreement may specify different types of defaults, such as failure to complete works within the agreed timeframe, failure to provide required documentation, financial defaults, or non-compliance with relevant regulations. The notice of default describes the specific nature of the breach, the corresponding clause or provision of the Section 278 Agreement that has been violated, and the necessary steps to rectify the default.
The template also highlights the potential consequences of the default, which could include financial penalties, suspension of the development project, or even termination of the Section 278 Agreement. It may also outline the dispute resolution process in case the developer wishes to contest the notice of default or negotiate alternative solutions.
This legal template is designed to provide clarity, structure, and consistency in addressing defaults under a Section 278 Agreement, ensuring that both parties are aware of their rights, obligations, and the necessary steps to remedy any breach. It is intended to serve as a guide for local authorities in maintaining accountability and enforcing compliance with the terms of the agreement between the council and the developer.
This template provides the necessary framework for the local authority to formally notify the developer when they are in breach of their obligations or have failed to adhere to the terms outlined in the Section 278 Agreement. The notice of default serves as a formal communication, triggering certain legal consequences to rectify the default and ensuring the progress of the development project.
The agreement may specify different types of defaults, such as failure to complete works within the agreed timeframe, failure to provide required documentation, financial defaults, or non-compliance with relevant regulations. The notice of default describes the specific nature of the breach, the corresponding clause or provision of the Section 278 Agreement that has been violated, and the necessary steps to rectify the default.
The template also highlights the potential consequences of the default, which could include financial penalties, suspension of the development project, or even termination of the Section 278 Agreement. It may also outline the dispute resolution process in case the developer wishes to contest the notice of default or negotiate alternative solutions.
This legal template is designed to provide clarity, structure, and consistency in addressing defaults under a Section 278 Agreement, ensuring that both parties are aware of their rights, obligations, and the necessary steps to remedy any breach. It is intended to serve as a guide for local authorities in maintaining accountability and enforcing compliance with the terms of the agreement between the council and the developer.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Rule 7.12 Certificate Of Compliance (Compulsory Liquidation Case)
The legal template for Rule 7.12 Certificate of Compliance (Compulsory Liquidation Case) under UK law is a standardized document used in the context of compulsory liquidation proceedings. Compulsory liquidation refers to the winding up of a company mandated by a court order, typically due to the company's inability to pay its debts.
Rule 7.12 of UK law governs the requirements and procedures relating to the submission of a Certificate of Compliance in such cases. This specific legal document serves as a confirmation from the appointed liquidator or the company's authorized representative that they have complied with all the necessary obligations and duties imposed by the court in the liquidation process.
The template will typically include essential details, such as the company name, court case number, and the relevant provisions of the law under which the liquidation is taking place. It will also highlight the key responsibilities and obligations that the liquidator has successfully fulfilled, such as notifying creditors, conducting investigations, preparing financial statements, and distributing assets.
This Certificate of Compliance provides assurance to the court and stakeholders that the compulsory liquidation case has been conducted in accordance with the requirements of UK law. It plays a crucial role in facilitating the legal closure of a company, ensuring transparency, and protecting the rights of creditors and interested parties involved in the liquidation process.
Rule 7.12 of UK law governs the requirements and procedures relating to the submission of a Certificate of Compliance in such cases. This specific legal document serves as a confirmation from the appointed liquidator or the company's authorized representative that they have complied with all the necessary obligations and duties imposed by the court in the liquidation process.
The template will typically include essential details, such as the company name, court case number, and the relevant provisions of the law under which the liquidation is taking place. It will also highlight the key responsibilities and obligations that the liquidator has successfully fulfilled, such as notifying creditors, conducting investigations, preparing financial statements, and distributing assets.
This Certificate of Compliance provides assurance to the court and stakeholders that the compulsory liquidation case has been conducted in accordance with the requirements of UK law. It plays a crucial role in facilitating the legal closure of a company, ensuring transparency, and protecting the rights of creditors and interested parties involved in the liquidation process.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
6
RATINGS
3
DISCUSSIONS
3
Winding-Up Petition Certificate of Service (Compulsory Liquidation Case Study)
The "Winding-Up Petition Certificate of Service (Compulsory Liquidation Case Study) under UK law" legal template is a document that pertains to the process of compulsory liquidation of a company in the United Kingdom.
Compulsory liquidation is a legal procedure initiated by a creditor or shareholders to force the winding-up of a company that is unable to pay its debts. The template specifically focuses on the certificate of service, which is a document required to prove that the winding-up petition has been properly served.
This legal template is designed to provide a standardized format for documenting and confirming the successful service of the winding-up petition to all relevant parties involved in the compulsory liquidation proceedings. It serves as evidence that the petition has been officially communicated to the company undergoing liquidation, its directors, and other stakeholders, ensuring compliance with UK law.
The certificate of service typically includes essential information such as the date, time, and place of service, along with details of the individual(s) who served the petition. It may also include information regarding any attempts made to serve the petition previously, ensuring that all parties involved have been duly notified.
By utilizing this legal template, businesses, legal professionals, or individuals involved in compulsory liquidation cases can streamline and maintain proper documentation for their proceedings, thereby ensuring that all necessary parties have been informed and legal obligations have been fulfilled in accordance with UK law.
Compulsory liquidation is a legal procedure initiated by a creditor or shareholders to force the winding-up of a company that is unable to pay its debts. The template specifically focuses on the certificate of service, which is a document required to prove that the winding-up petition has been properly served.
This legal template is designed to provide a standardized format for documenting and confirming the successful service of the winding-up petition to all relevant parties involved in the compulsory liquidation proceedings. It serves as evidence that the petition has been officially communicated to the company undergoing liquidation, its directors, and other stakeholders, ensuring compliance with UK law.
The certificate of service typically includes essential information such as the date, time, and place of service, along with details of the individual(s) who served the petition. It may also include information regarding any attempts made to serve the petition previously, ensuring that all parties involved have been duly notified.
By utilizing this legal template, businesses, legal professionals, or individuals involved in compulsory liquidation cases can streamline and maintain proper documentation for their proceedings, thereby ensuring that all necessary parties have been informed and legal obligations have been fulfilled in accordance with UK law.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
8
RATINGS
3
DISCUSSIONS
0
Section 75 Application For Adjudication And Relief From Stamp Duty
The legal template for a Section 75 Application for Adjudication and Relief From Stamp Duty under UK law is a document that outlines the process and form required to request the adjudication of a disputed stamp duty liability.
Stamp duty is a tax imposed on various types of transactions, commonly associated with the transfer of property or the execution of certain legal documents. In certain instances, taxpayers may disagree with the assessment made by the UK tax authorities regarding the applicable stamp duty liability.
This template serves as a guide to individuals or entities involved in a dispute with the tax authorities, providing a clear and structured format for submitting an application for adjudication. It outlines the necessary details that should be included, such as the name and contact information of the applicant, a description of the disputed transaction, underlying legal provisions, and any supporting evidence or documentation.
By utilizing this template, individuals or entities seeking relief from stamp duty can present a well-organized and comprehensive application for adjudication. This, in turn, enhances the likelihood of a fair and thorough evaluation of the dispute by the relevant authorities, potentially resulting in a reevaluation of the stamp duty liability and providing the opportunity to seek relief from any erroneous or excessive tax liabilities.
Stamp duty is a tax imposed on various types of transactions, commonly associated with the transfer of property or the execution of certain legal documents. In certain instances, taxpayers may disagree with the assessment made by the UK tax authorities regarding the applicable stamp duty liability.
This template serves as a guide to individuals or entities involved in a dispute with the tax authorities, providing a clear and structured format for submitting an application for adjudication. It outlines the necessary details that should be included, such as the name and contact information of the applicant, a description of the disputed transaction, underlying legal provisions, and any supporting evidence or documentation.
By utilizing this template, individuals or entities seeking relief from stamp duty can present a well-organized and comprehensive application for adjudication. This, in turn, enhances the likelihood of a fair and thorough evaluation of the dispute by the relevant authorities, potentially resulting in a reevaluation of the stamp duty liability and providing the opportunity to seek relief from any erroneous or excessive tax liabilities.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
9
RATINGS
5
DISCUSSIONS
3
