All Templates
Vary completion date
🏚️ Completion date variation
Property Completion Date Variation Agreement
Property Completion Date Variation Agreement
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Completion date variationBusiness activity
Vary completion dateA completion date variation is a change to the date that is specified in the contract for the project to be completed. This could be due to a number of reasons such as delays in the construction process. The completion date variation will usually result in an extension of time being granted to the contractor.
This legal template, the Property Completion Date Variation Agreement, is a document specifically designed to address modifications to the agreed completion date of a property transaction under the jurisdiction of UK law. In real estate transactions, there can be circumstances where unforeseen events or issues arise, causing delays in the original completion date stated in the initial agreement. This template serves as a formal contract between the parties involved, allowing them to mutually agree on a revised completion date.
The Property Completion Date Variation Agreement template comprises various clauses and sections, articulating the terms and conditions agreed upon by both the buyer and seller. These provisions typically cover crucial aspects such as the reason for the alteration, the new completion date, any associated penalties or costs resulting from the delay, and the obligations and liabilities of each party.
By utilizing this legally binding document, both the buyer and seller can ensure clarity regarding the revised timeframe for transferring ownership of the property. The template aims to protect the interests of all parties involved by outlining the adjustments necessary to accommodate the current circumstances and avoid any potential disputes or misunderstandings.
It is important to note that this legal template may be adapted to suit the specific requirements of the parties involved, and should ideally be drafted or reviewed by an experienced solicitor or legal professional well-versed in property law in the United Kingdom.
The Property Completion Date Variation Agreement template comprises various clauses and sections, articulating the terms and conditions agreed upon by both the buyer and seller. These provisions typically cover crucial aspects such as the reason for the alteration, the new completion date, any associated penalties or costs resulting from the delay, and the obligations and liabilities of each party.
By utilizing this legally binding document, both the buyer and seller can ensure clarity regarding the revised timeframe for transferring ownership of the property. The template aims to protect the interests of all parties involved by outlining the adjustments necessary to accommodate the current circumstances and avoid any potential disputes or misunderstandings.
It is important to note that this legal template may be adapted to suit the specific requirements of the parties involved, and should ideally be drafted or reviewed by an experienced solicitor or legal professional well-versed in property law in the United Kingdom.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Case Management Order (Employment Tribunal)
A Case Management Order (Employment Tribunal) is a legal template designed to outline the procedures and deadlines that govern the progression of a specific case within an Employment Tribunal in the United Kingdom. This document is typically prepared and issued by the tribunal itself or a presiding judge, with the aim of promoting an organized and fair process for all parties involved.
This template serves as a roadmap for the case, providing crucial instructions and guidelines that dictate each phase of the legal proceedings. It outlines the various stages, such as initial submissions, witness statements, evidence disclosure, and potential hearings, and sets forth specific deadlines by which each party must comply. Additionally, it may address any practical arrangements, such as the scheduling of conferences, site visits, or expert testimonies, ensuring the smooth progression of the case.
The Case Management Order is designed to streamline the legal process, encouraging the efficient use of time and resources. It helps the parties understand their roles and responsibilities, ensuring that all relevant information is submitted and disclosed within specified timelines. By implementing this template, the tribunal aims to maintain an organized and structured environment, facilitating the resolution of employment disputes in an impartial and fair manner, in accordance with UK employment laws and regulations.
This template serves as a roadmap for the case, providing crucial instructions and guidelines that dictate each phase of the legal proceedings. It outlines the various stages, such as initial submissions, witness statements, evidence disclosure, and potential hearings, and sets forth specific deadlines by which each party must comply. Additionally, it may address any practical arrangements, such as the scheduling of conferences, site visits, or expert testimonies, ensuring the smooth progression of the case.
The Case Management Order is designed to streamline the legal process, encouraging the efficient use of time and resources. It helps the parties understand their roles and responsibilities, ensuring that all relevant information is submitted and disclosed within specified timelines. By implementing this template, the tribunal aims to maintain an organized and structured environment, facilitating the resolution of employment disputes in an impartial and fair manner, in accordance with UK employment laws and regulations.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
11
RATINGS
5
DISCUSSIONS
1
Senior Employee Or Executive Employment Contract
This legal template pertains to the employment contract for a senior employee or executive under the jurisdiction of UK law. It is designed to outline the terms, conditions, and responsibilities that will govern the employment relationship between the company and the senior employee or executive. The template may cover various aspects, including the position's title, job description, reporting structure, and key duties and responsibilities. It will also likely address compensation, benefits, and any bonus or incentive schemes specific to the role. The contract may stipulate the working hours, leave entitlements, and any restrictive covenants or non-compete clauses that are applicable. Additionally, provisions concerning termination, notice periods, and post-employment obligations may be outlined in the contract. Ultimately, this template aims to establish a clear and legally binding agreement between the employer and the senior employee or executive, protecting the rights and interests of both parties in compliance with UK employment legislation.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
7
RATINGS
4
DISCUSSIONS
3
Employee's Notice Of Return From Maternaity Leave (Early Return)
This legal template is a document designed for use in the United Kingdom to facilitate the process of an employee's early return from maternity leave. Under UK law, employees are entitled to take a certain amount of maternity leave, but there may be instances where an employee wishes to return to work before the agreed-upon leave period ends.
The template is intended to be completed by the employee who seeks an early return from their maternity leave. It provides a standardized format for notifying the employer in writing about their decision to return to work before the end of their maternity leave period.
The document typically includes sections to enter the employee's personal details, such as their name, contact information, and the expected date of return. Additionally, it may include spaces for providing any relevant information regarding the employee's preferred working hours and the specific arrangements that need to be made to accommodate their early return.
The purpose of this template is to ensure that the employee's early return is properly documented and correctly handled according to UK employment laws. It helps establish clear communication between the employee and the employer, providing a record of the employee's decision and any requests or preferences they may have for their return to work. This document is essential for both parties to manage expectations, and it can serve as a reference point for any future discussions or potential disputes related to the early return from maternity leave.
The template is intended to be completed by the employee who seeks an early return from their maternity leave. It provides a standardized format for notifying the employer in writing about their decision to return to work before the end of their maternity leave period.
The document typically includes sections to enter the employee's personal details, such as their name, contact information, and the expected date of return. Additionally, it may include spaces for providing any relevant information regarding the employee's preferred working hours and the specific arrangements that need to be made to accommodate their early return.
The purpose of this template is to ensure that the employee's early return is properly documented and correctly handled according to UK employment laws. It helps establish clear communication between the employee and the employer, providing a record of the employee's decision and any requests or preferences they may have for their return to work. This document is essential for both parties to manage expectations, and it can serve as a reference point for any future discussions or potential disputes related to the early return from maternity leave.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
11
RATINGS
3
DISCUSSIONS
1
