Pay Less Notice (Construction Contract)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Pay less noticeBusiness activity
Pay less noticeA pay less notice is a notice served by a contractor to a sub-contractor that sets out the sum the contractor considers to be due under the sub-contract. The notice must be served before the final date for payment stated in the sub-contract. If the sub-contractor does not agree with the sum stated in the pay less notice, they can serve a notice of intention to withhold payment.
The Pay Less Notice (Construction Contract) is a legal template commonly used in the United Kingdom within the construction industry. This document serves as a formal notice to the contractor from the employer, highlighting the intention to pay an amount less than the sum usually invoiced for the completed work or ongoing project.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
Under UK law, construction contracts often involve interim payments based on the progress of the project. These payments are typically made in stages or intervals, and the Pay Less Notice template is utilized when the employer believes there are valid grounds to pay an amount less than the sum invoiced by the contractor for a particular payment period.
The notice provides the employer with a legal framework to contest issues such as defects, non-compliance with contractual obligations, or relevant variations undertaken by the contractor. It aims to address potential disputes or disagreements over the contractor's work quality, delays, or additional costs incurred.
When using this template, the employer is required to communicate the reasons and calculations for the reduction in payment. This notice period is typically outlined in the terms and conditions of the construction contract and must be delivered within a specified timeframe before the intended payment date. The Pay Less Notice allows the employer to exercise their contractual right to set off or deduct an appropriate amount from the contractor's interim payment.
Given the complexity of construction projects and the potential disputes that may arise, the Pay Less Notice (Construction Contract) template helps establish transparency and a structured approach to managing payment issues between employers and contractors under UK law.
How it works
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
Case Management Order (Employment Tribunal)
A Case Management Order (Employment Tribunal) is a legal template designed to outline the procedures and deadlines that govern the progression of a specific case within an Employment Tribunal in the United Kingdom. This document is typically prepared and issued by the tribunal itself or a presiding judge, with the aim of promoting an organized and fair process for all parties involved.
This template serves as a roadmap for the case, providing crucial instructions and guidelines that dictate each phase of the legal proceedings. It outlines the various stages, such as initial submissions, witness statements, evidence disclosure, and potential hearings, and sets forth specific deadlines by which each party must comply. Additionally, it may address any practical arrangements, such as the scheduling of conferences, site visits, or expert testimonies, ensuring the smooth progression of the case.
The Case Management Order is designed to streamline the legal process, encouraging the efficient use of time and resources. It helps the parties understand their roles and responsibilities, ensuring that all relevant information is submitted and disclosed within specified timelines. By implementing this template, the tribunal aims to maintain an organized and structured environment, facilitating the resolution of employment disputes in an impartial and fair manner, in accordance with UK employment laws and regulations.
This template serves as a roadmap for the case, providing crucial instructions and guidelines that dictate each phase of the legal proceedings. It outlines the various stages, such as initial submissions, witness statements, evidence disclosure, and potential hearings, and sets forth specific deadlines by which each party must comply. Additionally, it may address any practical arrangements, such as the scheduling of conferences, site visits, or expert testimonies, ensuring the smooth progression of the case.
The Case Management Order is designed to streamline the legal process, encouraging the efficient use of time and resources. It helps the parties understand their roles and responsibilities, ensuring that all relevant information is submitted and disclosed within specified timelines. By implementing this template, the tribunal aims to maintain an organized and structured environment, facilitating the resolution of employment disputes in an impartial and fair manner, in accordance with UK employment laws and regulations.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
11
RATINGS
5
DISCUSSIONS
1
Senior Employee Or Executive Employment Contract
This legal template pertains to the employment contract for a senior employee or executive under the jurisdiction of UK law. It is designed to outline the terms, conditions, and responsibilities that will govern the employment relationship between the company and the senior employee or executive. The template may cover various aspects, including the position's title, job description, reporting structure, and key duties and responsibilities. It will also likely address compensation, benefits, and any bonus or incentive schemes specific to the role. The contract may stipulate the working hours, leave entitlements, and any restrictive covenants or non-compete clauses that are applicable. Additionally, provisions concerning termination, notice periods, and post-employment obligations may be outlined in the contract. Ultimately, this template aims to establish a clear and legally binding agreement between the employer and the senior employee or executive, protecting the rights and interests of both parties in compliance with UK employment legislation.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
7
RATINGS
4
DISCUSSIONS
3
Employee's Notice Of Return From Maternaity Leave (Early Return)
This legal template is a document designed for use in the United Kingdom to facilitate the process of an employee's early return from maternity leave. Under UK law, employees are entitled to take a certain amount of maternity leave, but there may be instances where an employee wishes to return to work before the agreed-upon leave period ends.
The template is intended to be completed by the employee who seeks an early return from their maternity leave. It provides a standardized format for notifying the employer in writing about their decision to return to work before the end of their maternity leave period.
The document typically includes sections to enter the employee's personal details, such as their name, contact information, and the expected date of return. Additionally, it may include spaces for providing any relevant information regarding the employee's preferred working hours and the specific arrangements that need to be made to accommodate their early return.
The purpose of this template is to ensure that the employee's early return is properly documented and correctly handled according to UK employment laws. It helps establish clear communication between the employee and the employer, providing a record of the employee's decision and any requests or preferences they may have for their return to work. This document is essential for both parties to manage expectations, and it can serve as a reference point for any future discussions or potential disputes related to the early return from maternity leave.
The template is intended to be completed by the employee who seeks an early return from their maternity leave. It provides a standardized format for notifying the employer in writing about their decision to return to work before the end of their maternity leave period.
The document typically includes sections to enter the employee's personal details, such as their name, contact information, and the expected date of return. Additionally, it may include spaces for providing any relevant information regarding the employee's preferred working hours and the specific arrangements that need to be made to accommodate their early return.
The purpose of this template is to ensure that the employee's early return is properly documented and correctly handled according to UK employment laws. It helps establish clear communication between the employee and the employer, providing a record of the employee's decision and any requests or preferences they may have for their return to work. This document is essential for both parties to manage expectations, and it can serve as a reference point for any future discussions or potential disputes related to the early return from maternity leave.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
11
RATINGS
3
DISCUSSIONS
1
