All Templates
Carry out works
⛪ Licence to carry out works
Licence To Carry Out Works (Landlord Giving Consent)
Licence To Carry Out Works (Landlord Giving Consent)
Publisher one
Genie AIJurisdiction
England and WalesRelevant sectors
Type of legal document
⛪ Licence to carry out worksBusiness activity
Carry out worksThe License to Carry Out Works (Landlord Giving Consent) template is a legally binding document designed for use in the United Kingdom. This template outlines the consent given by a landlord to a tenant or another party, allowing them to carry out specific works or alterations on a property under the landlord's ownership.
The purpose of this template is to provide a formal agreement between the landlord and the party undertaking the works, ensuring that both parties have a clear understanding of their respective responsibilities and obligations. It establishes the terms and conditions under which the consent is given, including any restrictions or limitations on the type, scope, or duration of the proposed works.
This license document serves to protect the interests of the landlord, ensuring that the property is not subject to unauthorized or potentially damaging alterations. It enables the landlord to maintain control over their property and ensures that the works carried out comply with legal and regulatory requirements.
Key components included in this document typically cover details such as:
1. Identifying the parties involved: The template will require clarification of the landlord's and the tenant's or party carrying out the works' names and contact information. It may also include details regarding the property's address and description.
2. Defining the works: The license will outline the specific works that have been authorized, detailing what is permitted and what is not allowed. This can include, for instance, renovations, refurbishments, installations, or other alterations.
3. Duration: The agreed-upon time period during which the license to carry out works is valid will be clearly stated in the template. This ensures that the tenant or authorized party completes the works within the agreed timeframe.
4. Insurance and liabilities: The document may outline the insurance requirements, specifying the necessary coverage for the works being carried out. It may also allocate responsibilities for any damages, losses, or accidents related to the works.
5. Compliance with laws and regulations: The template will emphasize the need for the works to comply with all applicable laws, building regulations, planning permissions, and other legal obligations.
6. Security of the property: The license may include provisions for security, access control, and safeguarding the property during the works, specifying measures to protect the landlord's interests.
By utilizing this legal template, landlords can ensure that their property is protected while providing consent for necessary or desired works to be carried out. Similarly, it offers tenants or authorized parties a formal agreement, promoting clarity and understanding of their rights and obligations.
The purpose of this template is to provide a formal agreement between the landlord and the party undertaking the works, ensuring that both parties have a clear understanding of their respective responsibilities and obligations. It establishes the terms and conditions under which the consent is given, including any restrictions or limitations on the type, scope, or duration of the proposed works.
This license document serves to protect the interests of the landlord, ensuring that the property is not subject to unauthorized or potentially damaging alterations. It enables the landlord to maintain control over their property and ensures that the works carried out comply with legal and regulatory requirements.
Key components included in this document typically cover details such as:
1. Identifying the parties involved: The template will require clarification of the landlord's and the tenant's or party carrying out the works' names and contact information. It may also include details regarding the property's address and description.
2. Defining the works: The license will outline the specific works that have been authorized, detailing what is permitted and what is not allowed. This can include, for instance, renovations, refurbishments, installations, or other alterations.
3. Duration: The agreed-upon time period during which the license to carry out works is valid will be clearly stated in the template. This ensures that the tenant or authorized party completes the works within the agreed timeframe.
4. Insurance and liabilities: The document may outline the insurance requirements, specifying the necessary coverage for the works being carried out. It may also allocate responsibilities for any damages, losses, or accidents related to the works.
5. Compliance with laws and regulations: The template will emphasize the need for the works to comply with all applicable laws, building regulations, planning permissions, and other legal obligations.
6. Security of the property: The license may include provisions for security, access control, and safeguarding the property during the works, specifying measures to protect the landlord's interests.
By utilizing this legal template, landlords can ensure that their property is protected while providing consent for necessary or desired works to be carried out. Similarly, it offers tenants or authorized parties a formal agreement, promoting clarity and understanding of their rights and obligations.
How it works
Create doc / use template
Chat to our AI Legal Assistant
Edit, collaborate & share
Export to .docx
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
JCT Standard Building Contract (Without Quantities)
The JCT Standard Building Contract (Without Quantities) is a legal template specifically designed for construction projects carried out under the jurisdiction of UK law. This template serves as a binding agreement between the employer and the contractor, setting out the rights, responsibilities, and obligations of each party involved in the construction project.
The contract primarily focuses on the overall management and execution of the construction works, outlining the conditions, specifications, and requirements that need to be met by the contractor. As the name suggests, this particular template does not include detailed quantity measurements but provides a framework for the construction project as a whole.
Key provisions covered in this contract include responsibilities for the completion of the works, the management of variations and extensions of time, determination of the contract sum, and insurance requirements. It also outlines payment terms and mechanisms, addressing issues related to interim payments, retention, and final account settlements.
Additionally, the contract addresses matters concerning design responsibility, compliance with applicable laws and regulations, and coordination with any stakeholders involved in the project, such as architects and engineers. It also highlights procedures for dispute resolution, including alternative dispute resolution mechanisms and potential referral to arbitration.
Ultimately, this legal template provides a standardized framework that ensures the successful delivery of construction projects while offering protection for all parties involved, promoting fair and efficient project management, and reducing the potential for disputes or legal challenges.
The contract primarily focuses on the overall management and execution of the construction works, outlining the conditions, specifications, and requirements that need to be met by the contractor. As the name suggests, this particular template does not include detailed quantity measurements but provides a framework for the construction project as a whole.
Key provisions covered in this contract include responsibilities for the completion of the works, the management of variations and extensions of time, determination of the contract sum, and insurance requirements. It also outlines payment terms and mechanisms, addressing issues related to interim payments, retention, and final account settlements.
Additionally, the contract addresses matters concerning design responsibility, compliance with applicable laws and regulations, and coordination with any stakeholders involved in the project, such as architects and engineers. It also highlights procedures for dispute resolution, including alternative dispute resolution mechanisms and potential referral to arbitration.
Ultimately, this legal template provides a standardized framework that ensures the successful delivery of construction projects while offering protection for all parties involved, promoting fair and efficient project management, and reducing the potential for disputes or legal challenges.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
12
RATINGS
4
DISCUSSIONS
3
Standard Sub-Contract Conditions For Building (With Sub-Contractor's Design)
The legal template titled "Standard Sub-Contract Conditions For Building (With Sub-Contractor's Design) under UK law" is a comprehensive document that outlines the terms and conditions for sub-contracting work in the construction industry within the jurisdiction of the United Kingdom.
This template is specifically designed for construction projects where the sub-contractor is also responsible for the design aspects of the work. It establishes the rights, obligations, and liabilities of both the main contractor and the sub-contractor, ensuring clarity and protection for all parties involved.
The template covers a wide range of important provisions, including the scope of work, project progress, quality of materials and workmanship, pricing and payment terms, insurance requirements, delays and extensions of time, intellectual property rights, dispute resolution mechanisms, and termination of the sub-contract.
The document is legally enforceable and ensures compliance with relevant UK laws and regulations pertaining to the construction industry. It serves as a crucial tool for establishing a professional and mutually beneficial relationship between the main contractor and the sub-contractor, providing a framework for collaboration, accountability, and successful project completion.
This template is specifically designed for construction projects where the sub-contractor is also responsible for the design aspects of the work. It establishes the rights, obligations, and liabilities of both the main contractor and the sub-contractor, ensuring clarity and protection for all parties involved.
The template covers a wide range of important provisions, including the scope of work, project progress, quality of materials and workmanship, pricing and payment terms, insurance requirements, delays and extensions of time, intellectual property rights, dispute resolution mechanisms, and termination of the sub-contract.
The document is legally enforceable and ensures compliance with relevant UK laws and regulations pertaining to the construction industry. It serves as a crucial tool for establishing a professional and mutually beneficial relationship between the main contractor and the sub-contractor, providing a framework for collaboration, accountability, and successful project completion.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
12
RATINGS
3
DISCUSSIONS
1
Standard Sub-Contract Guide for Building
The "Standard Sub-Contract Guide for Building under UK Law" is a comprehensive legal template that outlines the necessary clauses and provisions for a subcontractor agreement in the construction industry within the jurisdiction of the United Kingdom. This template offers guidance and direction to parties involved in a building project, aiming to ensure clarity, fairness, and legal compliance in their contractual relationship.
This legal template covers various essential aspects of a subcontract agreement, including but not limited to:
1. Introduction and recitals: This section provides a brief background and context for the subcontract agreement, identifying the primary contractor, subcontractor, and their respective obligations and responsibilities.
2. Scope of work: Clearly defining the specific tasks and services the subcontractor is contracted to perform, including any specific timelines, milestones, or deliverables that must be met.
3. Payment terms: Detailing the agreed-upon payment structure, such as fixed price, time and material, or cost-plus arrangements, along with invoicing procedures, retention amounts (if any), and mechanisms for dispute resolution.
4. Performance standards: Outlining the quality standards and specifications the subcontractor has to adhere to while carrying out the assigned tasks, ensuring that the work meets the required level of skill, expertise, and compliance with relevant building codes and regulations.
5. Variation orders: Establishing a process for managing changes to the scope of work, including procedures for documenting and approving variations, impact on pricing and timelines, and any requirements for written consent from the primary contractor.
6. Insurance and liability: Defining the insurance coverage expectations and liabilities of the subcontractor, ensuring adequate protection for all parties involved, and outlining any indemnity provisions.
7. Termination and dispute resolution: Establishing the circumstances under which the subcontractor or primary contractor can terminate the agreement, including any notice periods required. Additionally, outlining the agreed methods for resolving disputes, such as negotiation, mediation, or arbitration.
8. Intellectual property and confidentiality: Addressing ownership rights of intellectual property related to the project and outlining any confidentiality obligations to protect proprietary information.
9. Health and safety: Ensuring compliance with relevant health and safety regulations and stipulating the subcontractor's responsibility for maintaining a safe working environment.
10. Governing law and jurisdiction: Specifying the law that governs the agreement and identifying the jurisdiction for any legal proceedings that may arise from the contract.
By utilizing the "Standard Sub-Contract Guide for Building under UK Law," parties involved in a building project can have a reliable and comprehensive legal framework to establish clear expectations, responsibilities, and rights for each party, supporting the smooth execution of the building contract and mitigating potential disputes and risks.
This legal template covers various essential aspects of a subcontract agreement, including but not limited to:
1. Introduction and recitals: This section provides a brief background and context for the subcontract agreement, identifying the primary contractor, subcontractor, and their respective obligations and responsibilities.
2. Scope of work: Clearly defining the specific tasks and services the subcontractor is contracted to perform, including any specific timelines, milestones, or deliverables that must be met.
3. Payment terms: Detailing the agreed-upon payment structure, such as fixed price, time and material, or cost-plus arrangements, along with invoicing procedures, retention amounts (if any), and mechanisms for dispute resolution.
4. Performance standards: Outlining the quality standards and specifications the subcontractor has to adhere to while carrying out the assigned tasks, ensuring that the work meets the required level of skill, expertise, and compliance with relevant building codes and regulations.
5. Variation orders: Establishing a process for managing changes to the scope of work, including procedures for documenting and approving variations, impact on pricing and timelines, and any requirements for written consent from the primary contractor.
6. Insurance and liability: Defining the insurance coverage expectations and liabilities of the subcontractor, ensuring adequate protection for all parties involved, and outlining any indemnity provisions.
7. Termination and dispute resolution: Establishing the circumstances under which the subcontractor or primary contractor can terminate the agreement, including any notice periods required. Additionally, outlining the agreed methods for resolving disputes, such as negotiation, mediation, or arbitration.
8. Intellectual property and confidentiality: Addressing ownership rights of intellectual property related to the project and outlining any confidentiality obligations to protect proprietary information.
9. Health and safety: Ensuring compliance with relevant health and safety regulations and stipulating the subcontractor's responsibility for maintaining a safe working environment.
10. Governing law and jurisdiction: Specifying the law that governs the agreement and identifying the jurisdiction for any legal proceedings that may arise from the contract.
By utilizing the "Standard Sub-Contract Guide for Building under UK Law," parties involved in a building project can have a reliable and comprehensive legal framework to establish clear expectations, responsibilities, and rights for each party, supporting the smooth execution of the building contract and mitigating potential disputes and risks.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
8
RATINGS
3
DISCUSSIONS
0
