All Countries
Real Estate
Standard General Contractor Agreement

Standard General Contractor Agreement Template for South Africa

Create a bespoke document in minutes,  or upload and review your own.

4.6 / 5
4.8 / 5

Let's create your Standard General Contractor Agreement

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Standard General Contractor Agreement

"I need a Standard General Contractor Agreement for a commercial office building construction project in Cape Town, South Africa, with specific emphasis on green building requirements and local community engagement, anticipated to commence in March 2025."

Celebrated by
Collaborations with
Investors
Document background
The Standard General Contractor Agreement is a fundamental legal document used in the South African construction industry to establish a contractual relationship between a project owner (Employer) and a General Contractor. This agreement is essential for any construction project where a main contractor is engaged to execute and manage construction works. It incorporates requirements from key South African legislation including the Construction Industry Development Board Act, Occupational Health and Safety Act, and National Building Regulations. The document is designed to protect both parties' interests while ensuring clear allocation of responsibilities, risk management, and project execution procedures. It is particularly suitable for medium to large-scale construction projects where detailed terms and conditions are necessary to govern the relationship between the parties and ensure successful project delivery.
Suggested Sections

1. Parties: Identification and details of the Employer and the Contractor, including registration numbers and physical addresses

2. Background: Context of the agreement and brief description of the project and parties' intentions

3. Definitions and Interpretation: Detailed definitions of terms used in the agreement and rules for interpreting the contract

4. Scope of Works: Detailed description of the construction works to be performed by the Contractor

5. Contract Price and Payment Terms: Agreement on pricing, payment schedule, variations, and payment procedures

6. Duration and Programme: Project timeline, completion dates, and programming requirements

7. Contractor's Obligations: General and specific obligations of the Contractor including quality standards and workmanship

8. Employer's Obligations: Responsibilities of the Employer including site access and information provision

9. Health and Safety: Safety requirements and responsibilities in compliance with OHS Act

10. Quality Control and Inspection: Quality standards, inspection procedures, and acceptance criteria

11. Variations: Procedures for handling changes to the scope of work

12. Extensions of Time: Circumstances allowing time extensions and related procedures

13. Defects Liability: Defects liability period and remediation procedures

14. Insurance and Indemnity: Required insurance coverage and indemnification provisions

15. Termination: Grounds and procedures for contract termination by either party

16. Dispute Resolution: Procedures for resolving disputes including mediation and arbitration

17. General Provisions: Standard legal provisions including notices, governing law, and entire agreement

Optional Sections

1. Performance Security: Requirements for performance bonds or guarantees, used for high-value projects

2. Environmental Management: Environmental protection requirements, needed for projects with significant environmental impact

3. Community Engagement: Local community involvement and communication requirements, important for public projects

4. Force Majeure: Provisions for unforeseen circumstances, particularly relevant in long-term projects

5. Intellectual Property: IP rights and obligations, needed when design or innovative methods are involved

6. Transformation Requirements: B-BBEE and local content requirements, essential for public sector projects

7. Liquidated Damages: Pre-determined damages for specific breaches, used in time-critical projects

8. Materials and Equipment: Specific provisions for materials and equipment supply, important for complex projects

9. Subcontracting: Rules and procedures for subcontracting, needed when subcontractors are anticipated

Suggested Schedules

1. Schedule A - Scope of Works: Detailed technical specifications and drawings

2. Schedule B - Pricing Schedule: Detailed breakdown of prices, rates, and quantities

3. Schedule C - Project Programme: Detailed project timeline and milestones

4. Schedule D - Site Information: Site details, access points, and specific site conditions

5. Schedule E - Health and Safety Specifications: Detailed health and safety requirements and procedures

6. Schedule F - Quality Management Plan: Quality control procedures and requirements

7. Schedule G - Insurance Requirements: Detailed insurance specifications and coverage requirements

8. Schedule H - Forms and Certificates: Standard forms for variations, completion certificates, etc.

9. Schedule I - Contractor's Personnel: Key personnel and their qualifications

10. Appendix 1 - Drawings: Complete set of construction drawings

11. Appendix 2 - Environmental Management Plan: Environmental protection procedures and requirements

12. Appendix 3 - Permits and Licenses: Copies of relevant permits and licenses

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Linkedin in social icon imageX social icon image
alex.den.21@genieai.co
Relevant legal definitions
Agreement
Appendices
Approved
As-Built Drawings
Bill of Quantities
Certificate of Completion
Certificate of Final Completion
Commencement Date
Completion Date
Construction Documents
Construction Period
Construction Programme
Contract Documents
Contract Price
Contract Works
Contractor
Contractor's Equipment
Contractor's Personnel
Day
Defects
Defects Liability Period
Delay Damages
Employer
Employer's Equipment
Employer's Requirements
Extension of Time
Final Account
Force Majeure
Good Industry Practice
Health and Safety Plan
Insurance Requirements
Intellectual Property Rights
Laws
Material
Milestone
Notice
Payment Certificate
Performance Security
Practical Completion
Principal Agent
Project
Project Manager
Quality Management Plan
Retention Money
Schedule of Rates
Site
Specifications
Subcontractor
Substantial Completion
Variation
Variation Order
Works
Working Day
Working Hours
Clauses
Interpretation
Appointment
Scope of Works
Contract Price
Payment Terms
Duration
Programme of Works
Site Access
Contractor Obligations
Employer Obligations
Materials and Workmanship
Quality Control
Health and Safety
Environmental Protection
Insurance
Indemnification
Performance Security
Variations
Extensions of Time
Force Majeure
Suspension
Termination
Defects Liability
Warranties
Intellectual Property
Confidentiality
Dispute Resolution
Notices
Assignment
Subcontracting
Compliance with Laws
Labor Relations
Site Security
Testing and Commissioning
Practical Completion
Final Completion
Risk Allocation
Liability
Documentation
Records and Audits
Governing Law
B-BBEE Requirements
Local Content
Entire Agreement
Relevant Industries

Commercial Construction

Residential Construction

Industrial Construction

Infrastructure Development

Mining Infrastructure

Retail Development

Healthcare Facilities

Educational Facilities

Government Infrastructure

Property Development

Renewable Energy Infrastructure

Transportation Infrastructure

Relevant Teams

Legal

Operations

Construction

Commercial

Procurement

Risk Management

Health and Safety

Quality Control

Project Management

Contract Administration

Technical

Finance

Relevant Roles

Construction Manager

Project Manager

Contract Manager

Legal Counsel

Quantity Surveyor

Site Manager

Commercial Manager

Risk Manager

Procurement Manager

Chief Operating Officer

Operations Director

Construction Director

Legal Director

Finance Director

Technical Director

Health and Safety Manager

Quality Control Manager

Project Engineer

Contracts Administrator

Business Development Manager

Industries
Construction Industry Development Board Act 38 of 2000: Provides for the establishment of the Construction Industry Development Board and regulates the construction industry, including contractor registration requirements and grading.
Occupational Health and Safety Act 85 of 1993: Governs workplace safety requirements and obligations, particularly relevant for construction activities and site safety management.
Compensation for Occupational Injuries and Diseases Act 130 of 1993: Provides for compensation in case of occupational injuries or diseases, mandatory for construction industry employers.
Basic Conditions of Employment Act 75 of 1997: Establishes basic conditions of employment, including working hours, leave, and other fundamental employment terms.
Labour Relations Act 66 of 1995: Regulates labor relations and collective bargaining, important for managing workforce in construction projects.
Broad-Based Black Economic Empowerment Act 53 of 2003: Promotes economic transformation and participation of black people in the South African economy, including construction sector requirements.
National Building Regulations and Building Standards Act 103 of 1977: Sets standards for building construction and necessary approvals required for construction works.
Consumer Protection Act 68 of 2008: Protects consumer rights and applies to construction contracts where the client is a consumer.
Value Added Tax Act 89 of 1991: Governs VAT obligations in construction contracts and payment structures.
Environmental Conservation Act 73 of 1989: Provides for environmental protection during construction activities and necessary environmental impact assessments.
Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

General Contractor Building Contract

A South African law-governed contract between an employer and general contractor establishing terms and conditions for construction project execution.

find out more

Construction Management Agency Contract

A South African construction contract establishing an agency relationship between a Principal and Construction Manager for professional project management services.

find out more

Simple Building Contract

A South African law-governed construction agreement for straightforward building projects, defining contractor and employer obligations while ensuring regulatory compliance.

find out more

Agreement And Conditions Of Contract For Building Works

A standardized building works contract compliant with South African construction law, governing the relationship between employer and contractor for construction projects.

find out more

Building Contract And Consultancy Agreement For A Home Owner Occupier

South African residential building and consultancy agreement for home owner-occupiers, combining construction terms with professional services provisions under local law.

find out more

Tripartite Agreement In (Construction)

A South African law-governed agreement establishing rights and obligations between three parties in a construction project, typically involving the owner, contractor, and financier/sub-contractor.

find out more

Standard General Contractor Contract

A South African law-governed construction agreement between property owners/developers and general contractors, outlining terms for construction project execution and management.

find out more

Residential Construction Management Agreement

South African agreement governing the relationship between property owner and construction manager for residential construction projects, defining services, responsibilities, and compliance requirements.

find out more

Project Management Agreement (Construction)

A South African law-governed agreement defining terms and conditions for construction project management services, including scope, responsibilities, and compliance requirements.

find out more

Building Contract

A South African law-governed agreement between an employer and contractor for construction works, detailing scope, payments, timeframes, and compliance requirements.

find out more

Home Construction Contract

A South African-compliant contract for residential property construction, establishing terms between property owner and contractor under local building regulations and NHBRC requirements.

find out more

Standard General Contractor Agreement

A South African law-governed agreement between an Employer and General Contractor establishing terms and conditions for construction works.

find out more

Standard Building Contract

A comprehensive construction agreement under South African law governing the relationship between employer and contractor for building projects.

find out more

Construction Warranty Agreement

A South African law-governed agreement that specifies construction warranty terms, conditions, and remedies for defects in completed construction work.

find out more

Construction Teaming Agreement

A South African law-governed agreement establishing collaboration between construction industry parties for joint project pursuit and execution, incorporating local regulatory and B-BBEE requirements.

find out more

Agreement For Construction Of House With Material

A South African law-governed agreement for residential house construction, including material provision, compliant with NHBRC requirements and local regulations.

find out more

Standard Contractors Agreement

A South African law-governed agreement establishing terms and conditions between a client and independent contractor for provision of services.

find out more

Contract Between Builder And Client

A South African law-governed construction agreement between a builder and client, detailing project scope, terms, and obligations while ensuring regulatory compliance.

find out more

Simple Construction Loan Agreement

A South African law-governed agreement for providing construction financing, incorporating lending terms and construction milestone requirements.

find out more

Agreement Between Land Owner And Builder

A South African construction contract between a property owner and builder, outlining terms, conditions, and regulatory compliance for building works.

find out more

Construction Payment Contract

A South African law-governed agreement establishing payment terms and procedures for construction projects, ensuring compliance with local construction regulations and protecting all parties' interests.

find out more

Basic Building Contract

A South African law-governed construction agreement defining the relationship between client and contractor for building projects, ensuring compliance with national building regulations.

find out more

Construction Service Agreement

A South African law-governed agreement establishing terms and conditions for construction services, ensuring compliance with local construction regulations and industry standards.

find out more

Construction Equipment Rental Agreement

A South African law-governed agreement for construction equipment rental, establishing terms between equipment owner and renter.

find out more

Construction Subcontract

A South African law-governed agreement between a main contractor and subcontractor defining terms for construction works execution.

find out more

Construction Management Contract

A South African law-governed agreement between Client and Construction Manager defining professional construction management services, responsibilities, and compensation.

find out more

Download our whitepaper on the future of AI in Legal

By providing your email address you are consenting to our Privacy Notice.
Thank you for downloading our whitepaper. This should arrive in your inbox shortly. In the meantime, why not jump straight to a section that interests you here: https://www.genieai.co/our-research
Oops! Something went wrong while submitting the form.

Genie’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; Genie’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

Our bank-grade security infrastructure undergoes regular external audits

We are ISO27001 certified, so your data is secure

Organizational security

You retain IP ownership of your documents

You have full control over your data and who gets to see it

Innovation in privacy:

Genie partnered with the Computational Privacy Department at Imperial College London

Together, we ran a £1 million research project on privacy and anonymity in legal contracts

Want to know more?

Visit our Trust Centre for more details and real-time security updates.

Read our Privacy Policy.