Cost Plus Residential Construction Contract Template for India

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Cost Plus Residential Construction Contract

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Cost Plus Residential Construction Contract

"I need a Cost Plus Residential Construction Contract for a luxury villa project in Bangalore starting March 2025, with specific provisions for sustainable building materials and LEED certification requirements, where the contractor's fee will be 12% of actual costs."

Document background

The Cost Plus Residential Construction Contract is designed for use in the Indian construction market where transparency in costs and contractor compensation is paramount. This contract type is particularly suitable for complex residential projects where exact costs are difficult to predetermine, or when projects require flexibility in scope. The agreement complies with Indian legislation including the Real Estate (Regulation and Development) Act 2016, the Indian Contract Act 1872, and relevant building and safety regulations. It provides detailed mechanisms for cost tracking, contractor fee calculation, change management, and quality control, while protecting both owner and contractor interests. The document is structured to accommodate various construction scenarios, from new builds to major renovations, and includes provisions for regulatory compliance, dispute resolution, and risk allocation specific to the Indian context.

Suggested Sections

1. Parties: Identification and details of the Owner and the Contractor, including their registered addresses and authorized representatives

2. Background: Context of the agreement, including property details and the Owner's intention to construct a residential building

3. Definitions and Interpretation: Definitions of key terms used in the contract and rules for contract interpretation

4. Scope of Work: Detailed description of the construction work to be performed by the Contractor

5. Cost Plus Structure: Definition of base costs and contractor's fee/markup percentage, including allowable and non-allowable costs

6. Payment Terms: Payment schedule, billing procedures, documentation requirements, and payment approval process

7. Time for Completion: Project timeline, milestone dates, and provisions for extensions of time

8. Contractor's Obligations: Key responsibilities including quality control, supervision, safety measures, and regulatory compliance

9. Owner's Obligations: Responsibilities including site access, approvals, and document provision

10. Materials and Workmanship: Quality standards, material specifications, and approval processes

11. Changes and Variations: Procedures for handling changes to scope, specifications, or costs

12. Insurance and Indemnity: Required insurance coverage and indemnification obligations

13. Defects Liability: Warranty period, defect rectification process, and quality guarantees

14. Termination: Grounds and procedures for contract termination by either party

15. Dispute Resolution: Mechanisms for resolving disputes, including mediation and arbitration procedures

16. General Provisions: Standard clauses including notices, governing law, and force majeure

Optional Sections

1. Acceleration of Work: Used when there might be a need to speed up construction, including terms for additional costs

2. Environmental Compliance: Include when project has specific environmental sensitivities or requirements

3. Sustainable Building Practices: Include when project aims for green building certification or specific sustainability goals

4. Subcontracting: Include when subcontractors are likely to be engaged, defining approval processes and responsibilities

5. Temporary Facilities: Include for larger projects requiring significant temporary structures or facilities

6. Site Security: Include for projects in sensitive areas or with specific security requirements

7. Antiquities and Artifacts: Include when construction is in historically significant areas

8. Owner Occupancy During Construction: Include when renovation work is being done with owner remaining in residence

Suggested Schedules

1. Schedule A - Property Details: Legal description of the property and site details

2. Schedule B - Construction Drawings and Specifications: Approved architectural and engineering drawings, technical specifications

3. Schedule C - Cost Breakdown Structure: Detailed breakdown of base costs and contractor's fee calculation methodology

4. Schedule D - Construction Schedule: Detailed timeline with milestones and critical path activities

5. Schedule E - List of Approved Materials: Specifications and brands of approved construction materials

6. Schedule F - Payment Schedule: Detailed payment terms, installment amounts, and timing

7. Schedule G - Insurance Requirements: Specific insurance types and coverage amounts required

8. Schedule H - Key Personnel: List of key contractor personnel assigned to the project

9. Appendix 1 - Required Permits and Approvals: List of necessary regulatory permits and approvals

10. Appendix 2 - Quality Control Procedures: Detailed quality assurance and control processes

11. Appendix 3 - Safety Procedures: Safety protocols and emergency procedures

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Construction

Real Estate

Residential Development

Architecture

Engineering

Construction Management

Building Materials

Property Development

Relevant Teams

Legal

Construction

Project Management

Procurement

Finance

Compliance

Risk Management

Quality Control

Commercial

Operations

Relevant Roles

Construction Manager

Project Director

Contract Administrator

Legal Counsel

Property Developer

Quantity Surveyor

Site Supervisor

Procurement Manager

Cost Controller

Risk Manager

Compliance Officer

Building Inspector

Chief Architect

Structural Engineer

Finance Manager

Project Coordinator

Find the exact document you need

Material Supply Contract In (Construction)

An Indian law-governed agreement establishing terms for construction material supply, including specifications, quality standards, delivery terms, and regulatory compliance requirements.

How a Sales & Marketing Lead uses Genie AI to reduce contract drafting time by 95%

Let's create your Cost Plus Residential Construction Contract

Authors

Alex Denne

Find the exact document you need

Material Supply Contract In (Construction)

Land Owner Builder Agreement

Labor Contract For (Construction)

Joint Development Agreement For (Construction)

Home Renovation Contractor Agreement

Cost Plus Residential Construction Contract

Contractor Agreement For House (Construction)

Building Contract And Consultancy Agreement For A Home Owner Occupier

Third Party Agreement (Construction)

Tripartite Agreement In (Construction)

Standard General Contractor Contract

Residential Construction Management Agreement

Simple Works Contract

Project Management Contract In (Construction)

Project Management Agreement (Construction)

Joint Venture Agreement For (Construction)

Independent Contractor Agreement For (Construction)

Generic Construction Contract

Construction Payment Agreement

Construction Agreement And Sale Agreement

Contract Between Contractor And Owner

Standard Contractor Contract

Construction Agreement Letter

Standard Building Contract

Real Estate Construction Contract

Construction Warranty Agreement

Contract Between Builder And Subcontractor

Construction Completion Agreement

Residential Construction Management Contract

Agreement Between Builder And Contractor

Landscape Contractor Contract

Contract Between Builder And Client

Agreement Between Two Contractors

Swimming Pool Construction Agreement

Standard Construction Agreement

Owner Builder Subcontractor Agreement

Construction Labor Contract Agreement

Construction Collaboration Agreement

Commercial Construction Agreement

General Contractor Contract With Owner

Construction Labor Agreement

Builder Development Agreement

Construction Payment Contract

Construction Lease Agreement

Contract For Contractor And Homeowner

Construction Equipment Lease Agreement

Basic Building Contract

Construction Work Order Agreement

Construction Project Agreement

Road Construction Agreement

Engineering Procurement And Construction Agreement

Construction Equipment Rental Agreement

Building Maintenance Agreement

Buyer Builder Agreement

Construction Partnership Agreement

Construction Employee Contract

Supply And Installation Agreement

Construction Subcontract

Construction Management Agreement

Remodeling Contractor Agreement

General Construction Agreement

Construction Management Contract

Cost Plus Construction Agreement

Access Agreement For (Construction)

Download our whitepaper on the future of AI in Legal

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security

Innovation in privacy:

Want to know more?

Commercial

Employment

IP

Administration