Construction Payment Contract Template for India

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Construction Payment Contract

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Construction Payment Contract

"I need a Construction Payment Contract for a residential high-rise project in Mumbai, with milestone-based payments and a 10% retention clause, ensuring compliance with RERA 2016 and including provisions for bank guarantees."

Document background

The Construction Payment Contract is a specialized agreement used in the Indian construction industry to regulate payment arrangements between parties involved in construction projects. This document is essential when establishing a formal payment structure for construction works, whether for commercial, residential, or infrastructure projects. It incorporates provisions compliant with Indian legislation, including the Indian Contract Act 1872, RERA 2016, and relevant construction industry regulations. The contract typically includes detailed payment schedules, milestone-based disbursements, retention provisions, and mechanisms for handling payment-related disputes. It's particularly important in protecting both parties' interests by providing clear payment terms, documentation requirements, and remedy procedures in case of payment defaults or disputes.

Suggested Sections

1. Parties: Identification of the contractor and client/employer with full legal details

2. Background: Context of the construction project and relationship between parties

3. Definitions: Definitions of key terms used throughout the contract

4. Scope of Work: Detailed description of the construction work to be performed

5. Contract Price: Total contract value and breakdown of costs

6. Payment Terms: Payment schedule, mechanisms, and conditions for payment

7. Payment Security: Requirements for bank guarantees, performance bonds, or other security measures

8. Milestones and Timeline: Key project milestones and completion deadlines

9. Quality Standards: Required quality standards and inspection procedures

10. Obligations of the Contractor: Detailed responsibilities and duties of the contractor

11. Obligations of the Employer: Detailed responsibilities and duties of the employer

12. Variations and Changes: Process for handling changes to scope or specifications

13. Delays and Extensions: Provisions for dealing with delays and time extensions

14. Default and Termination: Grounds and procedures for contract termination

15. Dispute Resolution: Procedures for resolving disputes including arbitration provisions

16. Governing Law: Specification of Indian law as governing law and jurisdiction

Optional Sections

1. Force Majeure: Provisions for unforeseen circumstances - include if project is long-term or in volatile areas

2. Insurance: Specific insurance requirements - include if not covered in main contractor agreement

3. Retention Money: Terms for retained payments - include for larger projects

4. Defects Liability: Post-completion liability period - include for complex construction works

5. Subcontracting: Rules for subcontracting - include if subcontracting is permitted

6. Environmental Compliance: Environmental obligations - include for environmentally sensitive projects

7. Labor Compliance: Detailed labor law compliance - include for labor-intensive projects

8. Site Access and Security: Site-specific access rules - include for restricted or sensitive locations

9. Materials and Equipment: Specific requirements for materials - include for specialized construction

10. Intellectual Property: IP rights in designs/plans - include for unique architectural works

Suggested Schedules

1. Schedule A - Payment Schedule: Detailed breakdown of payment installments and triggers

2. Schedule B - Construction Specifications: Technical specifications and construction requirements

3. Schedule C - Project Timeline: Detailed project schedule with milestones and deadlines

4. Schedule D - Quality Standards: Specific quality requirements and testing procedures

5. Schedule E - Bill of Quantities: Detailed list of quantities and rates for materials and work

6. Schedule F - Site Plan and Drawings: Technical drawings and site layout plans

7. Schedule G - Performance Security Format: Format for bank guarantees and performance bonds

8. Schedule H - Safety Standards: Safety requirements and procedures

9. Appendix 1 - Required Permits: List of necessary permits and approvals

10. Appendix 2 - Insurance Requirements: Detailed insurance coverage requirements

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Construction

Real Estate

Infrastructure Development

Commercial Property

Residential Development

Industrial Construction

Public Works

Transportation Infrastructure

Healthcare Infrastructure

Educational Infrastructure

Retail Development

Hospitality Construction

Manufacturing Facilities

Energy and Utilities

Smart Cities Development

Relevant Teams

Legal

Finance

Procurement

Operations

Construction

Project Management

Commercial

Risk and Compliance

Contract Administration

Business Development

Relevant Roles

Project Manager

Construction Manager

Contract Administrator

Finance Director

Chief Financial Officer

Legal Counsel

Procurement Manager

Site Engineer

Quantity Surveyor

Commercial Director

Operations Manager

Development Manager

Construction Director

Risk Manager

Compliance Officer

Find the exact document you need

Material Supply Contract In (Construction)

An Indian law-governed agreement establishing terms for construction material supply, including specifications, quality standards, delivery terms, and regulatory compliance requirements.

How a Sales & Marketing Lead uses Genie AI to reduce contract drafting time by 95%

Let's create your Construction Payment Contract

Authors

Alex Denne

Find the exact document you need

Material Supply Contract In (Construction)

Land Owner Builder Agreement

Labor Contract For (Construction)

Joint Development Agreement For (Construction)

Home Renovation Contractor Agreement

Cost Plus Residential Construction Contract

Contractor Agreement For House (Construction)

Building Contract And Consultancy Agreement For A Home Owner Occupier

Third Party Agreement (Construction)

Tripartite Agreement In (Construction)

Standard General Contractor Contract

Residential Construction Management Agreement

Simple Works Contract

Project Management Contract In (Construction)

Project Management Agreement (Construction)

Joint Venture Agreement For (Construction)

Independent Contractor Agreement For (Construction)

Generic Construction Contract

Construction Payment Agreement

Construction Agreement And Sale Agreement

Contract Between Contractor And Owner

Standard Contractor Contract

Construction Agreement Letter

Standard Building Contract

Real Estate Construction Contract

Construction Warranty Agreement

Contract Between Builder And Subcontractor

Construction Completion Agreement

Residential Construction Management Contract

Agreement Between Builder And Contractor

Landscape Contractor Contract

Contract Between Builder And Client

Agreement Between Two Contractors

Swimming Pool Construction Agreement

Standard Construction Agreement

Owner Builder Subcontractor Agreement

Construction Labor Contract Agreement

Construction Collaboration Agreement

Commercial Construction Agreement

General Contractor Contract With Owner

Construction Labor Agreement

Builder Development Agreement

Construction Payment Contract

Construction Lease Agreement

Contract For Contractor And Homeowner

Construction Equipment Lease Agreement

Basic Building Contract

Construction Work Order Agreement

Construction Project Agreement

Road Construction Agreement

Engineering Procurement And Construction Agreement

Construction Equipment Rental Agreement

Building Maintenance Agreement

Buyer Builder Agreement

Construction Partnership Agreement

Construction Employee Contract

Supply And Installation Agreement

Construction Subcontract

Construction Management Agreement

Remodeling Contractor Agreement

General Construction Agreement

Construction Management Contract

Cost Plus Construction Agreement

Access Agreement For (Construction)

Download our whitepaper on the future of AI in Legal

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security

Innovation in privacy:

Want to know more?

Commercial

Employment

IP

Administration