Standard Building Contract (Estimated Quantities)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏷️ Building contractBusiness activity
Build a structureA building contract is a legal agreement between a homeowner and a contractor that outlines the scope of work, timeline, and cost of a home improvement project. The contract should include provisions for payment, change orders, and a dispute resolution process. A well-written contract protects both the homeowner and the contractor by clearly defining the expectations and responsibilities of each party.
The template outlines the rights, responsibilities, and obligations of both parties involved in the construction project. It covers various aspects of the contract, including project specifications, estimated quantities, pricing, payment terms, variations, completion deadlines, and dispute resolution mechanisms.
The contract template adopts the commonly used JCT (Joint Contracts Tribunal) standard form and incorporates provisions that are compliant with UK construction law and regulations. It ensures that both parties are aware of their respective obligations, expectations, and legal rights throughout the construction process.
The contract template also addresses important issues such as liability for defects, insurance requirements, health and safety considerations, and intellectual property rights. It defines the procedures for handling changes in project scope, pricing adjustments, and additional works, ensuring that any modifications to the original contract are properly documented and agreed upon by both parties.
Ultimately, the Standard Building Contract (Estimated Quantities) under UK law provides a comprehensive framework for the smooth execution of construction projects, safeguarding the interests of both the client and the contractor, and establishing clear guidelines for successful project completion while complying with the relevant legal requirements in the United Kingdom.
How it works
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Book your personalised demo now
Similar legal templates
Takeover Schedule
Publisher
Genie AIJurisdiction
England and WalesStandard Sub-Contract Conditions For Building (With Sub-Contractor's Design)
This template is specifically designed for construction projects where the sub-contractor is also responsible for the design aspects of the work. It establishes the rights, obligations, and liabilities of both the main contractor and the sub-contractor, ensuring clarity and protection for all parties involved.
The template covers a wide range of important provisions, including the scope of work, project progress, quality of materials and workmanship, pricing and payment terms, insurance requirements, delays and extensions of time, intellectual property rights, dispute resolution mechanisms, and termination of the sub-contract.
The document is legally enforceable and ensures compliance with relevant UK laws and regulations pertaining to the construction industry. It serves as a crucial tool for establishing a professional and mutually beneficial relationship between the main contractor and the sub-contractor, providing a framework for collaboration, accountability, and successful project completion.
Publisher
Genie AIJurisdiction
England and WalesTest Engineer Contract
This Test Engineer contract template is designed for a commercial testing organisation (or an individual test engineer) to use when contracting out their skills and services in exchange for payment. This contract sets out the type of testing and testing-related services to be completed by the test engineer on behalf of the client, with consideration for expectations around quality and delivery timescales, as well as any mitigating circumstances. This contract allows for payment to be made by the client to the testing firm or individual test engineer on a weekly or monthly basis but can easily be edited to account for other payment schedules and could be altered to include bonuses conditional on performance. It can also be fully customised with the details of the two parties and the duration of the contract and can be printed, downloaded and edited freely as part of our mission to open source business legals. This is a template for contractors who fit outside of the UK's off-payroll working rules (IR35).
