Deed of Mutual Covenant (Flying Freehold)
Publisher one
Genie AIJurisdiction
England and WalesCost
Free to useRelevant sectors
Type of legal document
🏚️ Deed of covenantBusiness activity
Protect flying freeholdThe legal template "Deed of Mutual Covenant (Flying Freehold) under UK law" is a legally binding agreement between two or more parties involved in a property ownership arrangement known as a "flying freehold" in the United Kingdom.
A flying freehold refers to a unique situation where a portion of one property is built or extends over another property, creating overlapping spaces or shared structures between the two. This can commonly occur in buildings such as apartments or terraced houses.
The purpose of this legal template is to establish specific terms and conditions that govern the relationship and responsibilities of the parties involved in the flying freehold arrangement. It will outline the respective rights, obligations, and restrictions applicable to both the owner of the flying freehold (the building or extension owner) and the owner of the underlying property (the property beneath the flying freehold).
The Deed of Mutual Covenant serves to ensure a harmonious coexistence, as well as the proper maintenance, use, and enjoyment of the shared areas or structures. It may cover various important aspects, such as:
1. Boundaries and Shared Spaces: Clearly defining the boundaries between the flying freehold and the underlying property, as well as identifying and specifying shared spaces, walls, roofs, common entrances or exits, and any other shared facilities or amenities.
2. Maintenance and Repairs: Establishing the responsibilities for repairs, renovations, and maintenance of the shared areas. It may outline how costs will be apportioned, including details on regular contributions to a sinking fund or reserve fund for such purposes.
3. Alterations and Changes: Providing guidelines and procedures for making alterations or modifications to the flying freehold or the shared spaces, including ensuring that adequate permissions or approvals are obtained.
4. Access and Rights of Way: Addressing any rights of access, easements, or rights of way required for maintenance, use, or emergency situations, and clarifying the conditions under which they may be exercised.
5. Dispute Resolution: Prescribing methods for resolving disputes that may arise between the parties, including mediation or arbitration, to prevent the escalation of conflicts and facilitate amicable solutions.
As the legal framework for a flying freehold can be quite complex, this template aims to provide a standard document that can be customized according to the specific needs and circumstances of the individual flying freehold arrangement. It ensures that the rights and obligations of each party are clearly defined and legally enforceable, offering clarity and protection to all involved.
A flying freehold refers to a unique situation where a portion of one property is built or extends over another property, creating overlapping spaces or shared structures between the two. This can commonly occur in buildings such as apartments or terraced houses.
The purpose of this legal template is to establish specific terms and conditions that govern the relationship and responsibilities of the parties involved in the flying freehold arrangement. It will outline the respective rights, obligations, and restrictions applicable to both the owner of the flying freehold (the building or extension owner) and the owner of the underlying property (the property beneath the flying freehold).
The Deed of Mutual Covenant serves to ensure a harmonious coexistence, as well as the proper maintenance, use, and enjoyment of the shared areas or structures. It may cover various important aspects, such as:
1. Boundaries and Shared Spaces: Clearly defining the boundaries between the flying freehold and the underlying property, as well as identifying and specifying shared spaces, walls, roofs, common entrances or exits, and any other shared facilities or amenities.
2. Maintenance and Repairs: Establishing the responsibilities for repairs, renovations, and maintenance of the shared areas. It may outline how costs will be apportioned, including details on regular contributions to a sinking fund or reserve fund for such purposes.
3. Alterations and Changes: Providing guidelines and procedures for making alterations or modifications to the flying freehold or the shared spaces, including ensuring that adequate permissions or approvals are obtained.
4. Access and Rights of Way: Addressing any rights of access, easements, or rights of way required for maintenance, use, or emergency situations, and clarifying the conditions under which they may be exercised.
5. Dispute Resolution: Prescribing methods for resolving disputes that may arise between the parties, including mediation or arbitration, to prevent the escalation of conflicts and facilitate amicable solutions.
As the legal framework for a flying freehold can be quite complex, this template aims to provide a standard document that can be customized according to the specific needs and circumstances of the individual flying freehold arrangement. It ensures that the rights and obligations of each party are clearly defined and legally enforceable, offering clarity and protection to all involved.
How it works
Create doc / use template
Chat to our AI Legal Assistant
Edit, collaborate & share
Export to .docx
PRODUCT HUNT
#1 Product of the Day
Try using Genie's Free AI Legal Assistant
Generate quality, formatted contracts with AI
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
Let our Legal AI make edits for you
Ask Genie to edit your document in the same way you’d ask a paralegal. Genie makes track changes, and explains its thinking just like a junior lawyer would.
AI review
Can’t find the right template? Create the bespoke agreement in minutes by conversing with our AI and tailoring to your needs
See Genie AI in action
Book your personalised demo now
Schedule a live, interactive demo with a Genie expert
Understand the most valuable features of Genie based on your workflow
Find out exactly how your business will benefit, from hours saved to faster revenue
Similar legal templates
JCT Standard Building Contract (Without Quantities)
The JCT Standard Building Contract (Without Quantities) is a legal template specifically designed for construction projects carried out under the jurisdiction of UK law. This template serves as a binding agreement between the employer and the contractor, setting out the rights, responsibilities, and obligations of each party involved in the construction project.
The contract primarily focuses on the overall management and execution of the construction works, outlining the conditions, specifications, and requirements that need to be met by the contractor. As the name suggests, this particular template does not include detailed quantity measurements but provides a framework for the construction project as a whole.
Key provisions covered in this contract include responsibilities for the completion of the works, the management of variations and extensions of time, determination of the contract sum, and insurance requirements. It also outlines payment terms and mechanisms, addressing issues related to interim payments, retention, and final account settlements.
Additionally, the contract addresses matters concerning design responsibility, compliance with applicable laws and regulations, and coordination with any stakeholders involved in the project, such as architects and engineers. It also highlights procedures for dispute resolution, including alternative dispute resolution mechanisms and potential referral to arbitration.
Ultimately, this legal template provides a standardized framework that ensures the successful delivery of construction projects while offering protection for all parties involved, promoting fair and efficient project management, and reducing the potential for disputes or legal challenges.
The contract primarily focuses on the overall management and execution of the construction works, outlining the conditions, specifications, and requirements that need to be met by the contractor. As the name suggests, this particular template does not include detailed quantity measurements but provides a framework for the construction project as a whole.
Key provisions covered in this contract include responsibilities for the completion of the works, the management of variations and extensions of time, determination of the contract sum, and insurance requirements. It also outlines payment terms and mechanisms, addressing issues related to interim payments, retention, and final account settlements.
Additionally, the contract addresses matters concerning design responsibility, compliance with applicable laws and regulations, and coordination with any stakeholders involved in the project, such as architects and engineers. It also highlights procedures for dispute resolution, including alternative dispute resolution mechanisms and potential referral to arbitration.
Ultimately, this legal template provides a standardized framework that ensures the successful delivery of construction projects while offering protection for all parties involved, promoting fair and efficient project management, and reducing the potential for disputes or legal challenges.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
12
RATINGS
4
DISCUSSIONS
3
Standard Sub-Contract Conditions For Building (With Sub-Contractor's Design)
The legal template titled "Standard Sub-Contract Conditions For Building (With Sub-Contractor's Design) under UK law" is a comprehensive document that outlines the terms and conditions for sub-contracting work in the construction industry within the jurisdiction of the United Kingdom.
This template is specifically designed for construction projects where the sub-contractor is also responsible for the design aspects of the work. It establishes the rights, obligations, and liabilities of both the main contractor and the sub-contractor, ensuring clarity and protection for all parties involved.
The template covers a wide range of important provisions, including the scope of work, project progress, quality of materials and workmanship, pricing and payment terms, insurance requirements, delays and extensions of time, intellectual property rights, dispute resolution mechanisms, and termination of the sub-contract.
The document is legally enforceable and ensures compliance with relevant UK laws and regulations pertaining to the construction industry. It serves as a crucial tool for establishing a professional and mutually beneficial relationship between the main contractor and the sub-contractor, providing a framework for collaboration, accountability, and successful project completion.
This template is specifically designed for construction projects where the sub-contractor is also responsible for the design aspects of the work. It establishes the rights, obligations, and liabilities of both the main contractor and the sub-contractor, ensuring clarity and protection for all parties involved.
The template covers a wide range of important provisions, including the scope of work, project progress, quality of materials and workmanship, pricing and payment terms, insurance requirements, delays and extensions of time, intellectual property rights, dispute resolution mechanisms, and termination of the sub-contract.
The document is legally enforceable and ensures compliance with relevant UK laws and regulations pertaining to the construction industry. It serves as a crucial tool for establishing a professional and mutually beneficial relationship between the main contractor and the sub-contractor, providing a framework for collaboration, accountability, and successful project completion.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
12
RATINGS
3
DISCUSSIONS
1
Standard Sub-Contract Guide for Building
The "Standard Sub-Contract Guide for Building under UK Law" is a comprehensive legal template that outlines the necessary clauses and provisions for a subcontractor agreement in the construction industry within the jurisdiction of the United Kingdom. This template offers guidance and direction to parties involved in a building project, aiming to ensure clarity, fairness, and legal compliance in their contractual relationship.
This legal template covers various essential aspects of a subcontract agreement, including but not limited to:
1. Introduction and recitals: This section provides a brief background and context for the subcontract agreement, identifying the primary contractor, subcontractor, and their respective obligations and responsibilities.
2. Scope of work: Clearly defining the specific tasks and services the subcontractor is contracted to perform, including any specific timelines, milestones, or deliverables that must be met.
3. Payment terms: Detailing the agreed-upon payment structure, such as fixed price, time and material, or cost-plus arrangements, along with invoicing procedures, retention amounts (if any), and mechanisms for dispute resolution.
4. Performance standards: Outlining the quality standards and specifications the subcontractor has to adhere to while carrying out the assigned tasks, ensuring that the work meets the required level of skill, expertise, and compliance with relevant building codes and regulations.
5. Variation orders: Establishing a process for managing changes to the scope of work, including procedures for documenting and approving variations, impact on pricing and timelines, and any requirements for written consent from the primary contractor.
6. Insurance and liability: Defining the insurance coverage expectations and liabilities of the subcontractor, ensuring adequate protection for all parties involved, and outlining any indemnity provisions.
7. Termination and dispute resolution: Establishing the circumstances under which the subcontractor or primary contractor can terminate the agreement, including any notice periods required. Additionally, outlining the agreed methods for resolving disputes, such as negotiation, mediation, or arbitration.
8. Intellectual property and confidentiality: Addressing ownership rights of intellectual property related to the project and outlining any confidentiality obligations to protect proprietary information.
9. Health and safety: Ensuring compliance with relevant health and safety regulations and stipulating the subcontractor's responsibility for maintaining a safe working environment.
10. Governing law and jurisdiction: Specifying the law that governs the agreement and identifying the jurisdiction for any legal proceedings that may arise from the contract.
By utilizing the "Standard Sub-Contract Guide for Building under UK Law," parties involved in a building project can have a reliable and comprehensive legal framework to establish clear expectations, responsibilities, and rights for each party, supporting the smooth execution of the building contract and mitigating potential disputes and risks.
This legal template covers various essential aspects of a subcontract agreement, including but not limited to:
1. Introduction and recitals: This section provides a brief background and context for the subcontract agreement, identifying the primary contractor, subcontractor, and their respective obligations and responsibilities.
2. Scope of work: Clearly defining the specific tasks and services the subcontractor is contracted to perform, including any specific timelines, milestones, or deliverables that must be met.
3. Payment terms: Detailing the agreed-upon payment structure, such as fixed price, time and material, or cost-plus arrangements, along with invoicing procedures, retention amounts (if any), and mechanisms for dispute resolution.
4. Performance standards: Outlining the quality standards and specifications the subcontractor has to adhere to while carrying out the assigned tasks, ensuring that the work meets the required level of skill, expertise, and compliance with relevant building codes and regulations.
5. Variation orders: Establishing a process for managing changes to the scope of work, including procedures for documenting and approving variations, impact on pricing and timelines, and any requirements for written consent from the primary contractor.
6. Insurance and liability: Defining the insurance coverage expectations and liabilities of the subcontractor, ensuring adequate protection for all parties involved, and outlining any indemnity provisions.
7. Termination and dispute resolution: Establishing the circumstances under which the subcontractor or primary contractor can terminate the agreement, including any notice periods required. Additionally, outlining the agreed methods for resolving disputes, such as negotiation, mediation, or arbitration.
8. Intellectual property and confidentiality: Addressing ownership rights of intellectual property related to the project and outlining any confidentiality obligations to protect proprietary information.
9. Health and safety: Ensuring compliance with relevant health and safety regulations and stipulating the subcontractor's responsibility for maintaining a safe working environment.
10. Governing law and jurisdiction: Specifying the law that governs the agreement and identifying the jurisdiction for any legal proceedings that may arise from the contract.
By utilizing the "Standard Sub-Contract Guide for Building under UK Law," parties involved in a building project can have a reliable and comprehensive legal framework to establish clear expectations, responsibilities, and rights for each party, supporting the smooth execution of the building contract and mitigating potential disputes and risks.
Read More
Publisher
Genie AIJurisdiction
England and WalesTEMPLATE
USED BY
8
RATINGS
3
DISCUSSIONS
0